Questions and Replies
06 October 2016 - NW1932
Redelinghuys, Mr MH to ask the Minister of Police
(1)Whether owners of firearms are required to sign forms indemnifying (a) any SA Police Service (SAPS) official, (b) the SAPS and/or (c) the Government of any (i) responsibility and/or (ii) legal action that may arise as a result of the firearm being in their possession when handing firearms over to the SAPS; if not, why not; if so, what are the relevant details; (2) what standard procedures has his department put in place for handing firearms over to the SAPS?
Reply:
(1) Yes, a person who is legally entitled to possess a firearm or ammunition in terms of the Firearms Control Act, 60 of 2000 and who is the owner of the firearm or ammunition may surrender that firearm or ammunition to (a) a police official (b) of the South African Police Service by the handing over of the firearm or ammunition to (c) a police station together with the applicable licence, permit or authorisation, together with the applicable form (SAPS 522 (a) – Surrendering of Firearm Item(s)).
(1)(i)-(ii) In all instances where a firearm or ammunition is surrendered to a police station, the circumstances may be investigated to establish whether an offence has been committed with or in respect of such firearm or ammunition. A receipt must be handed over to the person from whom the firearm and ammunition is received.
(2) National Instruction 3/2002 regulates the surrendering of firearms and/or ammunition to the South African Police Service.
06 October 2016 - NW1935
Waters, Mr M to ask the Minister of Police
(a) Why are two unmarked police cars with certain registration numbers (details furnished) regularly visiting a certain property (details furnished), (b) how many times have the specified vehicles visited the specified property since 1 January 2016 and (c) what are the names of the SA Police Service officers who operate from the specified vehicles?
Reply:
(a) The mentioned vehicles do not belong to the South African Police Service.
(b) Not applicable.
(c) Not applicable.
06 October 2016 - NW1936
Van Der Walt, Ms D to ask the Minister of Police
(a) Why were weapons discharged three times between 24 November 2015 and 1 August 2016 at a certain address (details furnished) and (b) who was responsible for discharging of weapons in each case?
Reply:
(a) According to the resident at the mentioned address, no shooting took place during the said period.
(b) Not applicable.
06 October 2016 - NW1931
Redelinghuys, Mr MH to ask the Minister of Police
(1)(a) What is the current status of the investigation into CAS 110/8/2014 opened at the Mabopane Police Station and (b) what are the charges contained in the docket; (2) whether any suspects have been arrested to date; if not, why not; if so, what are the relevant details in each case; (3) whether any (a) suspects or (b) witnesses have been interviewed; if not, why not, in each case; if so, (i) when and (ii) what are the further relevant details in each case; (4) when is the investigation anticipated to be finalised?
Reply:
(1)(a) The case docket Mabopane CAS 110/08/2014 is still under investigation and currently on the court roll at the Ga-Rankuwa Magistrate’s Court.
(1)(b) The charge in this case docket is Rape.
(2) Yes, a suspect was arrested on 11 August 2014. The suspect failed to appear in court on the remand date. However, he was traced in prison on 21 April 2016 and appeared in court on that day. The case against the accused was remanded to 27 September 2016 to allow the defence to obtain copies of the content of the case docket.
(3)(a) Yes, the arrested suspect was interviewed on 11 August 2014 and a warning statement was obtained from him.
(3)(b) Yes, witnesses were interviewed on 11 August 2014 and 9 September 2014 and their statements obtained.
(3)(b)(i) The suspect was interviewed on 11 August 2014.
The witnesses were interviewed on 11 August 2014 and 9 September 2014 respectively.
(3)(b)(ii) The arrested suspect’s warning statement and statements from the witnesses were obtained.
(4) The investigation is concluded and a trial date must be determined.
05 October 2016 - NW2100
Majola, Mr TR to ask the Minister of Public Enterprises
What amount did (a) her department and (b) each entity reporting to her spend on advertising on the (i) Africa News Network 7 channel, (ii) SA Broadcasting Corporation (aa) television channels and (bb) radio stations, (iii) national commercial radio stations and (iv) community (aa) television and (bb) radio stations (aaa) in the 2015-16 financial year and (bbb) since 1 April 2016?
Reply:
(a)
DPE |
spend |
period |
(i) ANN7 |
Nil |
|
(ii) SABC (aa) (bb) Ukhozi FM |
Nil R174 676.50 |
(aaa) (bbb) |
(iii) National commercial radio stations Ukhozi FM |
R174 676.50 |
(bbb) |
(iv) Community (aa) Cape TV B (bb) Radio Teemaneng Capricorn FM Nongoma FM Nkomazi FM Radio KC Radio NFM Barberton CR Radio Riverside |
R91 200 R11 750 R120 270 R35 416.65 R22 500 R15 700 R28 462 R25 000 R34 200 |
(aaa) (aaa) (aaa) (aaa) (aaa) (aaa) (aaa) (aaa) (aaa)
|
(b)
SAX |
Spend |
Period |
(i) ANN7 |
SA Express did not pay for advertising on the channel |
(aaa) & (bbb |
(ii) SABC (aa) (bb) Motsweding FM SAfm RSG |
SA Express did not advertise on SABC television channels R208 980 R15 255 R92430 |
(aaa) Current financial year Current financial year |
(iii) National commercial radio stations North West FM 702 |
R118 260 R124 814 |
(aaa) Current Financial year |
Transnet |
Spend |
Period |
(i) ANN7 |
Nil |
(aaa) and (bbb) |
(ii) SABC (aa) (bb) |
Nil R384 082.42 R1 951 130 |
(aaa) and (bbb) (aaa) (bbb) |
(iii) National commercial radio stations |
Nil R469 440 |
(aaa) (bbb) |
(iV0 Community (aa) (bb) |
Nil R111 937.44 Nil |
(aaa)-(bbb) (aaa) (bbb) |
Eskom |
Spend |
Period |
(i) ANN7 |
Nil |
|
(ii) SABC (aa) (bb) |
R16 million R8 million R2.4 million R5.5 million |
(aaa) (bbb) (bbb) (aaa) |
(iii) National commercial radio stations |
R9.8 million R6.24 million |
(aaa) (bbb) |
(iv) Community (aa) |
R3.5 million R1.1 million |
(aaa) (bbb) |
Alexkor |
Spend |
Period |
|
Nil |
|
(bb) |
Nil Nil |
|
(i) National commercial radio stations |
Nil |
|
(ii) Community (aa) (bb) |
Nil Nil Nil |
(aaa) (bbb) |
Denel |
Spend |
Period |
(i) ANN7 |
Nil |
|
(ii) Sabc (aa) (bb) |
Nil R363 327.35 |
|
(iii) National commercial radio stations |
R363 327.35 |
|
(iv) Community (aa) (bb) |
Nil R140 520 R74 646.96 |
(aaa) (bbb) |
Safcol |
Spend |
Period |
(i) ANN7 |
Nil |
|
(ii) Sabc (aa) (bb) |
Nil Nil |
|
(iii) National commercial radio stations |
Nil |
|
(iv) Community (aa) (bb) |
Nil Nil |
(aaa) (bbb) |
05 October 2016 - NW1867
Kopane, Ms SP to ask the Minister of Public Works
Did his department submit all documents and information required by the National Treasury for the purpose of determining the total cost of upgrades to the homestead of the President, Mr Jacob G Zuma, in Nkandla, as tasked by the Constitutional Court; if not, why not; if so, what are the relevant details?
Reply:
The Minister of Public Works:
Yes, the Department of Public Works (DPW) did submit all documents and other pieces of information in its possession that were required by the National Treasury. The latter received full cooperation from the DPW in the transmission of the documents. Before the Publication of the National Treasury Report the DPW was not informed about any incompleteness of documentation submitted to the National Treasury.
A newspaper article that appeared in the Sowetan of 28 June, 2016, erroneously created the impression that the DPW had attempted to stifle the investigation by the National Treasury. In the latter’s report, which was submitted to the Constitutional Court on 27 June, 2016, there is neither a statement nor allegation whatsoever that the DPW withheld information or documentation in its possession from the National Treasury or its consultants.
05 October 2016 - NW1776
Kohler-Barnard, Ms D to ask the Minister of Public Works
With regard to the 2014-15 Annual Report of the Council for the Built Environment, which noted that 213 new disciplinary cases were reported in the specified financial year, in each case, (a) what was the reason for the disciplinary cases, (b) how long did it take to resolve, (c) what were the outcomes and (d) what penalties were given?
Reply:
The Minister of Public Works
(a) The Council for the Built Environment (CBE) annual report states that a total of 213 complaints were received during the year under review. However, after an auditing process the correct number of 218 complaints was recorded. The Built Environment Professional Councils (BEPCs) do take disciplinary action against registered persons alleged to have violated any of the six Acts of Law governing the operations of BEPCs, as well as their respective codes of conduct. They are also empowered to take action against any person whose conduct is regarded as posing a danger to the health and safety of the public within the realm of the built environment.
The reasons for disciplinary cases relate to:
- Improper conduct;
- failure of registered persons to perform professional services within a reasonable time frame;
- professionals undertaking professional work while their registration is suspended;
- competency/design errors; and
- non-compliance with the Code of Conduct.
(b) Most of the cases took more than 90 days to complete. The average time from the date of lodgment to the date of finalisation of cases for the Engineering Council of South Africa (ECSA) is 180 days. The turnaround time is acknowledged as a challenge. This is mainly due to the high cost of investigations and conducting of disciplinary cases. Another challenge is that of a lack of legal resources within the BEPCs. BEPCS are then forced to source the assistance from lawyers outside the organisation.
(c) Out of the 218 complaints received, 131 (61%) complaints were finalised, while 87 (39%) were still in progress and 8 were withdrawn.
(d) The BEPCs’ disciplinary or accountability processes vary from one another. For instance, a matter may be closed without sanction or disciplinary action may be taken. Sanctions can take a number of forms and may be imposed singularly or in combination.
(Please see Annexure A and B for specified outcomes per case)
Penalties include:
- Reprimand or censure: reprimand and censure are similar in that they are official records, indicating that a licensee has been disciplined. They may, in themselves, not hamper one’s ability to practice, but may be imposed along with other penalties.
- Citation: the BEPC of the registered person may impose a fine or order of bargain, in lieu of making a formal accusation.
- Cease and desist order: an order to stop a particular activity or else face a penalty.
- Warning: this can be accompanied by stipulations or specific requirements.
- Mandated continuing education.
- Remediation: an attempt to correct practice and promote safety; it may define terms for the registered person to be reinstated in good standing.
- Referral to an alternative-to-discipline programme.
- Probation: during probation, the registered person may or may not be permitted to practice. If the registered person is permitted to remain in practice during the period of probation, it is with terms and conditions or restrictions.
- Suspension: a period of time in which a registered person may not practice or hold him/herself out.
ANNEXURE A
Number of Complaints received and their nature |
Completed |
In progress |
Total - (42) Breach of the SACQSP Code of Conduct
Contravening of Act 49 / 2000 – Clause 18(2)
Performing the work of a PrQS but not being registered (16) |
Mr J. Mpambela – candidate working for own account – fined Mr R. Van Wyk – fined Mr M.Z.C. Buyeye – fined and censured Jacques Olivier – candidate working for own account – fined R & G Consultants – branch not managed by a PrQS – corrected Raphael Bagarette / Jade Hare of Granbuild – candidates misrepresenting their status - corrected |
Disciplinary Stuart Ray – Unprofessional conduct Anthony Porter – Unprofessional conduct (awaiting evidence) Jayshenie Govender – failed to uphold the letter of supervisor undertaking Siseko Quantity Surveyors cc – unprofessional conduct Lwazi Msani – candidate caught cheating in the Professional Skills Module Exams |
Number of complaints withdrawn |
1 |
Mr A.S. Van Wyk – theft of funds – the matter was handled incorrectly in terms of procedure and has to recommence from the beginning. A former Registrar failed to issue a formal charge sheet within the 5-years since the complaint arose. |
Total – 112
|
Number of Registered Professionals who were sanctioned to a fine including suspended fines:
;
R1 300.00 of this amount is suspended for one year;
R1 600.00;
Number of cases reported to the SAPS - 30 |
Registered professionals with pending settlement agreements: SACAP v Michael Liebenberg SACAP v Sophia Holloway SACAP v Andre Griessel Registered professionals who have been cautioned and/or reprimanded: Piotr Plebankiewics Raynier Lewis Danie Kruger Margueretta Bekker Alista van Rooyen Registered professionals whose registrations have been withdrawn: Mongi Mbili Ganesan Govender Lizwe Mabutho Isaac Masotsha |
Number of complaints withdrawn |
0 |
|
Total - 4
|
1 complaint of advertisement of services as a Pr CHSA, Pr CM, Pr CPM and PrC mentor even though not registered in any of these categories. The Council has no jurisdiction over unregistered persons, however, it was decided that a formal caution be issued to the person concern to desist from doing so and that if he continues, such misrepresentation, then the Council reserved its right to pursue action against them. |
1 case was against an unregistered person practicing as Project Manager and since Council has no jurisdiction over unregistered persons no further action was deemed necessary. 1 case of misconduct against a registered person, which upon investigation was deemed to be unproven, hence the complaint was dismissed. 1 case of misconduct against a registered person who upon being requested to provide additional information to substantiate his allegation refused to do so hence this has been put on hold until such time that he provides the information requested from him. |
Number of complaints withdrawn |
0 |
|
Total - 15 complaints of improper conduct 1 complaint against an unregistered person |
0 |
Inaccurate valuations, candidates conducting valuations without (proper) supervision, misleading advertising, Fraud, Inefficient discharging of duties, Conflict of interest, Breach of contract, Failure to hand down appeal Board decision, Theft of client’s property Unfair labour practice |
Number of complaints withdrawn |
7 |
The complainants withdrew their cases |
None |
ANNEXURE B - ECSA
NO. |
RESPONDENT |
MERITS OF INVESTIGATION |
DATE COMPLAINT RECEIVED (year, month, date and number) |
OUTCOME OF INVESTIGATING COMMITTEE |
1. |
R Brittnell against A J Killian Pr Tech Eng (8870177) |
It is alleged that the Respondent as an official of the Local Authority, responsible for tender documents scrapped certain requirements of a tender and that” his actions directly deprived consulting engineering companies the opportunity to participate in a fair tender process”. |
(2012/11/20 - 32) |
The Investigating Committee considered the matter and was of the opinion that there was no prima facie evidence of improper conduct by the Respondent. |
2. |
BRS & R A Wilson obo BRS Wilson Family Trust against D A Rees Pr Eng (790430) |
It is alleged that the Respondent, appointed to facilitate a township development, created an unacceptable conflict of interest and failed to carry out his engineering responsibilities with the required degree of competence. |
(2013/05/13 – 16) |
The Investigating Committee considered the matter and were of the opinion that there was insufficient prima facie evidence of improper conduct by the Respondent. |
3. |
W Strydom obo Avondans Home Owners Association (AHOA) against F J Klomp Pr Eng (830442) |
It is alleged that the Respondent rendered professional services to the Developer for the Avondans Development in the construction of the roads. The development was taken over by AHOA. A crack appeared in the road whereafter AHOA employed an independent engineering service to do an investigation and provide a report on their findings. The report indicated that standard construction procedures were not followed. The Respondent denied responsibility and refused to guarantee the quality of his work. |
(2013/06/27 - 27) |
The Investigating Committee considered the matter and was of the opinion that there was insufficient prima facie evidence of improper conduct by the Respondent. |
4. |
H P Heath against R L Keudel-Schaffer Pr Tech Eng (200170125) |
The Respondent issued a completion certificate for a roof which had been repaired. The said roof was subsequently found to be defective. |
(2012/05/11-12) |
The Complainant withdrew the complaint, but due to the number of complaints received against the Respondent, the matter was referred to PROTT as part of their brief. |
5. |
ECSA against E J Pieters Pr Cert Eng (201290010) |
Improper Conduct |
(2013/11/07 - 47) |
The Investigating Committee considered the Respondent’s formal apology. |
6. |
E Maritz against J Erwee Pr Eng (950433) |
It is alleged that the Respondent was appointed as the responsible engineer for the Complainant’s home. A dispute arose between the builder and the owner and the Respondent who was appointed by the builder refuses to issue the completion certificate. |
(2013/12/10 - 54) |
There was insufficient evidence of improper conduct by the Respondent. |
7. |
C M F Rawlins against Messrs M S Moodley Pr Tech Eng (9340122), S Naidu Pr Eng (20010315) and R J Young Pr Eng (702868) |
The Complainant was issued a notice alleging that his gazebo caused the failure of his neighbour’s wall.
|
(2014/02/12 – 04) |
The Investigating Committee considered the Assignee’s recommendations and were of the opinion that there was insufficient evidence of improper conduct by the Respondents. |
8. |
(2014/02/12 – 05) |
|||
9. |
(2014/02/12 –06) |
|||
10. |
A D Barratt against A Mitchell Pr Tech Eng (877066) |
It is alleged that the Complainant pointed out inconsistencies and irregularities in the alteration of his neighbour’s home. A stop works order was issued which led to the Respondent sending a “threatening” email to the Complainant. |
(2013/09/30 – 41) |
A Peer Counselling meeting was successfully concluded with the Respondent on 23 April 2014 and the Peer Counselling Report was received. |
11. |
P Venter against H S Van Der Walt Pr Eng (860204) |
The Respondent was appointed as the engineer to conduct engineering work on the foundation, floor slab and stairs of the Complainant’s dwelling. The said structures demonstrated defects. |
(2013/03/26 – 08) |
The Assignee’s report was considered by the Investigating Committee which resolved that there was no evidence of improper conduct by the Respondent. |
12. |
A Solomon against L C Smith Pr Eng (860253) |
It is alleged that the Respondent undertook work without the Complainant’s consent or approval of the building plans along the Complainant’s boundary wall. The Respondent’s client is the Complainant’s neighbour. |
(2013/07/08 - 29) |
The Assignee’s verbal report was considered by the Investigating Committee which resolved that there was no evidence of improper conduct by the Respondent. |
13. |
N E Wana against J F G Fourie Pr Eng (870038) |
It is alleged that the Respondent constantly requested his own contractor to be appointed to the project. When this was not done, he found fault with the work done by the builder. The Respondent on ascertaining that an independent engineer was appointed by the owner withdrew his completion certificate. |
(2013/08/02 – 32) |
A response from the Complainant was not forthcoming despite numerous requests from the administration. To close the matter. |
14. |
J D Scheepers against J M van den Berg Pr Eng (790409) |
The Complainant is a contractor who was employed to do additions to a house. Towards completion of the work, the Complainant experienced some problems with the homeowner. The Complainant then requested the homeowner to pay for the labour and material used and the homeowner refused. The homeowner then brought in the Respondent. It is alleged the Respondent, in inspecting the work done by the Complainant, failed to apply his professional skills and that his opinions were subjective. |
(2013/08/07 – 35) |
The Investigating Committee considered the Expert and Assignee’s report and resolved that there was no evidence of improper conduct by the Respondent. |
15. |
Dr A van Rensburg Pr Eng against Prof R Sandenbergh Pr Eng (790475) |
It was alleged that the Respondent did not comply in accordance with the OHS Act when the Complainant addressed safety hazards with the Respondent during construction of the University. The Respondent allegedly did not adhere to requirements in respect of the appointment of personnel nor did he inform ECSA’s accreditation committee of the employee’s non-registration status and qualifications. It is further alleged that the Respondent “intentionally lied” in an affidavit regarding a formal grievance lodged by the Complainant. |
(2014/02/12 - 08) |
Substantiating information was not forthcoming from the Complainant. That the safety issues were addressed with the Respondent and further information with regards thereto supplied by the administration. |
16. |
R Ramphal against V K Ori Pr Tech Eng (9470055) |
It is alleged that the Respondent submitted a payment certificate which was above the tendered price. |
(2014/02/27 - 10) |
That the Investigating Committee considered the matter and resolved that the matter is of a commercial nature. |
17. |
A Parsotham against T W Harper Pr Eng (940368) |
Subsequent to the builder absconding, a new builder was tasked to assess and repair the damages resulting in a dispute with the engineer. It is alleged by the Complainant that “the internal walls and trenches were non-existent; the soil was not compacted before the slab was cast; the slab had various defects and that the walls were cracking and had to be pulled down”. A completion certificate was issued on 23 August 2013 in respect of the foundations. |
(2014/04/22 - 16) |
That the Investigating Committee consider the matter and resolved that there was no prima facie evidence of improper conduct by the Respondent. |
18. |
I C van der Vyver Pr Eng against M J Marais Pr Eng (940375) |
The Respondent, an employee of Arcus Gibb, was appointed by the client to undertake an administrative and regulatory audit of the Complainant’s project. The client subsequently terminated the appointment of the Complainant’s company and appointed the Respondent’s company for the said project. It is alleged that the Respondent was not furnished with a copy of the audit report for comment. |
(2013/08/07 – 34) |
A Peer Counselling meeting was successfully concluded with the Respondent. |
19. |
D Sibiya against J C van Tonder Pr Eng (750430) |
It is alleged that the Respondent was appointed as the responsible engineer for a first floor slab and staircase to the Complainant’s property for which he issued a completion certificate despite defects to the staircase and the slab which is on the brink of collapse. |
(2013/05/29 – 18) |
That the Peer Counselling Meeting was successfully concluded with the Respondent. |
20. |
S Sewchuran against D Rammanhor Pr Tech Eng (201270056) |
The Respondent was responsible for the design of the neighbour’s retaining walls. The Complainant alleges that excavation took place onto her property by the Respondent’s client. The Complainant approached the Local Authority regarding safety issues and was advised that back filling appeared to have been done which needed to be removed by her. The Complainant alleges that the wall built poses a danger to her property and vehicles. |
(2014/05/26 - 23) |
The Assignee’s verbal report was considered by the Investigating Committee which concluded that there was no evidence of improper conduct by the Respondent. |
21. |
G Strydom v J N M Barker Pr Eng (750309) |
It is alleged that the respondent designed the lateral support system supporting an 8 metre sand bank on the complainant’s northern property boundary. No permission was given for the lateral support. An independent engineering report concluded that the building work carried out on this plot encroached over the common boundary line onto the complainant’s property and has resulted in a potential collapse of the existing dwelling. |
(2014/02/11 - 03) |
No prima facie evidence of improper conduct. |
22. |
G van Wyk v N Barnard Pr Eng (870461) |
It is alleged that the Respondent signed off a temporary inspection certificate for temporary pavilions erected for the North West University for a rugby match. A large amount of spectators were expected at the final rugby match. Before the main event, one of the temporary pavilions collapsed whilst the spectators were sitting thereon. No injuries were reported and an inspection was undertaken of all the other temporary pavilions, which were subsequently declared unsafe. |
(2014/05/14 - 21) |
No prima facie evidence of improper conduct. |
23. |
W D Niewoudt v C F Joubert Pr Eng (800192) |
The complainant purchased a property off-plan. A week after the complainant discovered that the surface bed had cracks all over, the brickwork was not up to standard and dimensions were not the same as on the approved plans. It is alleged that the responsible engineer is Mr C F Joubert. |
(2014/09/04 – 31) |
Insufficient evidence of improper conduct from the complainant. |
24. |
J Morebudi v D R Veldtman Pr Techni Eng (9740088) |
It is alleged that the respondent is helping the second bidder by supplying them with confidential information regarding the project. It is further alleged that the respondent signed the completion certificate while he was registered as a technician. |
(2014/09/04 – 32) |
No prima-facie evidence of improper conduct. |
25. |
G van der Merwe against C H Magson Pr Tech Eng (770101) |
The Respondent allegedly used the Complainant’s (an architect and member of the SACPCMP) registration details without the Complainant’s knowledge which allowed him to secure a tender with the Free State Department of Education. |
(2013/11/20 - 52) |
That the advisory letter would be forwarded to the respondent. |
26. |
J Di Mambro against R L Keudel-Schaffer Pr Tech Eng (200170125) |
It is alleged that the Respondent undertook the design and supervision of a residential apartment complex during 2003/2004. It is further alleged that the Respondent failed to adhere to acceptable standards regarding the adequacy, quality and suitability of a large sub-surface channel which crosses the site diagonally below the residential apartment complex. |
(2014/01/20 - 01) |
That a Terms letter was issued to the complainant informing him that failure to respond timeously would result in the case being dismissed. |
27. |
J J van Niekerk against S P Cilliers Pr Eng (980363), W Kruger Pr Tech Eng (200570100) and J T Pidgeon Pr Eng (780227) |
It is alleged that the Respondents were involved in the development of a complex in Bloemfontein. It is further alleged that building plans for the complex were not approved and building plans were not submitted for a septic tank at the back of the complex which is running into the Renoster River. |
(2014/02/27 – 11) |
That there was insufficient evidence of improper conduct. |
28. |
||||
29. |
(2014/02/27 – 12) |
|||
(2014/02/27 – 13) |
||||
30. |
G Rossouw against C F Joubert Pr Eng (800192) |
The Respondent was appointed to do the structural design and erection supervision of a building in Magaliesburg. It is alleged that the Respondent did not indicate that the contractor deviated from the manufacturer’s instructions. Subsequent to a site visit by the Respondent, during which he advised that work could continue, the floor slab collapsed. |
(2014/03/14 - 15) |
I was found there was prima facie evidence of improper conduct. |
31. |
S Manuier against L L Ashton Pr Eng (870461) |
It is alleged that the Respondent refused to certify the work of the Complainant who installed a slab on the approval of the owner without the Respondent having seen the requisite drawings and/or plans. The Respondent was requested to provide reasons for his actions. This negatively impacted on the Complainant’s business. |
(2014/05/12 - 19) |
There was insufficient evidence of improper conduct. |
32 |
S Chilwan against J C Krogscheepers Pr Eng (920021), P J Bullock Pr Eng (840217) and R H Botha Candidate Pr Eng (20095007) |
It is alleged that the Respondents acted in breach of the contract entered into between the City of Cape Town and Lumen Technologies CC (the Complainant’s Close Corporation) by amongst others, communicating directly with contractors without the consent of the CC, incurring expenses for the CC, etc. |
(2014/06/13 – 24) |
There was insufficient evidence of improper conduct. |
33. |
||||
34. |
(2014/06/13 – 25) |
|||
(2014/06/13 – 26) |
||||
35. |
D Palm against B J Oosthuizen Pr Eng (20050191) |
It was alleged that the respondent canvassed and contracted to do work other than what he was trained and qualified for, such as underpinning to structures, executing concrete sub-contract works, as well as structural sub-contract works . That conflict of interest exists where the Respondent accepted appointments from both the client as a Professional Engineer and from the main contractor (complainant) for the underpinning concrete works and structural installations. It was further alleged that the respondent was unwilling to issue the completion certificate. |
(2014/07/04 – 28) |
That there was insufficient evidence of improper conduct. |
36. |
R Manaraj against B Ansell Pr Eng (980726) |
The respondent representing Clickscales Maughan-Brown (CMB) Electrical and Mechanical Engineers was appointed by Raj Maharajh Associates (RMA), representing the RMA Professional Consortium. It is alleged that the Respondent colluded with a Project Manager of Coega Development Corporation (CDC), which was the client of (RMA) in receiving a payment of R298 683.84 without informing RMA and thus resulted in losses to other members of the RMA Consortium. |
(2014/08/21 – 30) |
There was insufficient evidence of improper conduct. |
37. |
H H Page against D P Odendaal Pr Tech Eng (9970121) |
The complainant lodged a complaint with Eskom, regarding the publication by some engineers of Eskom on Magnitech Xenon lamp products. During Eskom’s investigation of the above, the Complainant was introduced to the Respondent as an expert. It is alleged that the respondent was not objective and did not apply professional engineering judgement to the case. |
(2014/09/04 – 33) |
There was insufficient evidence of improper conduct. |
38. |
H H Page against P M Smit Pr Eng (970373), B G M Van Wyk Pr Tech Eng (9270025) and S R Sishuba Pr Eng (980711) |
It was alleged that the Respondents published false information regarding Magnitech Xenon Sodium lamp products without any scientific basis. |
(2014/09/04 – 34) |
There was insufficient evidence of improper conduct. |
39. |
||||
40. |
(2014/09/04 – 35) |
|||
(2014/09/04 – 36) |
||||
41. |
D G Naidoo against N J King Pr Eng (930184) |
The Respondent was appointed as the consulting engineer on a project to review and design work. It is alleged that the Respondent reviewed the Complainant’s design without informing him. The Respondent’s report was said to be biased leading to the immediate dismissal of the Complainant on the project. The Client also refused to pay the Complainant for outstanding fees and the complainant suffered loss of income and credibility as a result thereof. The Respondent was said to have compromised the position of the Complainant by his actions, which were solely for the Respondent’s benefit. |
(2014/09/23 – 40) |
There was insufficient evidence of improper conduct. |
42. |
C van Dyk v J C van Tonder Pr Eng (750403) |
The Respondent allegedly allowed an unregistered person to sign off completion certificates, using Respondent’s profession credentials. |
(2011/02/08-60) |
No prima facie evidence of improper conduct. |
43. |
Dr T Scholtz v J R Müller Pr Eng (760565) & J G Claassen Pr Eng (910241) |
It is alleged that the first Respondent acted as both contractor and registered professional in respect of the Complainant’s home. The first Respondent did not disclose this conflict of interest to the Complainant. The first Respondent then proceeded to act as an expert witness acting on behalf of the second Respondent after being suspended by the NHBRC. It was alleged that the second Respondent acting as an expert witness, made incorrect statements regarding the boundary walls and damp proofing throughout the dwelling. |
(2013/10/28 – 42) |
No prima facie evidence of improper conduct. |
44. |
||||
(2013/10/28 – 43) |
||||
45. |
M Ungerer against J Singh Pr Tech Eng (200170137) |
The Respondent signed off a completion certificate whilst not attending to any site inspections. It is further alleged that the respondent stated that the A19 was not a legally binding document and that he had no contractual obligations to fulfill as the complainant was not his client. |
(2013/11/07 – 53) |
Insufficient evidence of improper conduct from the complainant. |
46. |
R Lees v M M B van Rooyen Pr Eng (880203) |
It is alleged that the Respondent was appointed as the competent person for the design of a reinforced concrete raft foundation, which has since developed major cracks. The Complainant alleged that the Respondent was not accepting responsibility for the failure of the foundations. |
(2014/05/12 – 18) |
No prima-facie evidence of improper conduct. |
04 October 2016 - NW2044
Figg, Mr MJ to ask the Minister in The Presidency: Women
What formal qualifications does each of her department’s (a)(i) Chief Financial Officers and/or (ii) acting Chief Financial Officers and (b)(i) Directors-General and/or (ii) acting Directors-General possess?
Reply:
(a)(i) B. Compt. (transferred to another Department at the end of September 2016)
(b)(i) Master of Arts (Sociology) and Masters in Security Studies.
________________________
Approved by the Minister on
Date………………………..
04 October 2016 - NW1123
Chance, Mr R to ask the Minister of Small Business Development
(1)What (a) amount was budgeted for the National Gazelles Programme in the 2015-16 financial year and (b) is the breakdown of how the specified budget was spent in the specified financial year;
Reply:
(a) The total amount budgeted for the National Gazelles Programme for the year 2015-16 is R R 22 085 000.00
(2) What (a) amount has been budgeted for the specified programme in the 2016-17 financial year and (b) is the breakdown of how the specified budget will be spent;
a) The total amount budgeted for the National Gazelles Programme for the year 2016-17 is R R 20 300 000.00
(3) What are the names of the selection panelists who are responsible for evaluating the applications and making the final selections in each province?
Province |
Institution |
Representative |
Free State |
SEDA |
B Mshumpila |
Jackie Ntshingila |
||
Free State Development Corporation |
Mafee Mokhethi |
|
Ernst Young |
JJ du Toit |
|
Barry Fichardt |
||
Mangaung Chamber of Commerce & Industry |
Samuel Galela |
|
Traction |
Karen Kuhlcke |
|
Limpopo |
SEDA |
Peter Maredi |
Koenie Slabbert |
||
Limpopo Economic Development Agency |
Karabo Kolobe |
|
Limpopo Business Forum |
Nady Thelele |
|
Eastern Cape |
SEDA |
Zuko Somtunzi |
Mtiya |
Zukile Nomafu |
|
Eastern Cape Development Corporation |
Zoliswa Mnqokoyi |
|
Mpumalanga |
SEDA |
Ntokozo Majola |
National Empowerment Fund |
Kgaugelo Sibiya |
|
Bongani Qokose |
||
SEFA |
Sabelo Mamba |
|
Lowvelt Chamber of Business & Tourism |
T Welem |
|
Kwa-Zulu Natal |
SEDA |
C Mnguni |
Ithala |
Mzondo |
|
R Naidoo |
||
D Gpapal |
||
Success Avenue (ED Expert) |
B Ntlabathi |
|
Kingdom Estate (ED Expert) |
E Nhliziyo |
|
Gauteng |
SAICA |
Mandisi Nombembe Puseletso Modimogale Sabelo Qupe |
University of Johannesburg |
Dr Pule Kholopane |
|
Business Place |
Udesh Sewrpersad |
|
Shaun Govender |
||
Small Business Development Institute |
KB Motlhoioa |
|
C Kadlodlo |
||
C Kujekwga |
||
Thabo Sebeko |
||
Charles Madzindu |
||
Industry Experts |
I Neethling |
|
R Kalain |
||
John Francis |
||
North West/ Northern Cape |
SEDA |
Mr maimane |
M Moseki |
||
North West Development Corporation |
WJ Wanzi |
|
Industrial Development Corporation |
K Magan |
|
Western Cape |
SEDA
|
Alex Qunta |
Ivor Hendrics |
||
Kiewit Mhlongo |
||
Matthew Bertram |
||
SEFA |
Zandile Nyawo |
|
Anglo Zimele |
Portia Zilwa |
|
|
Bonita Daniels |
|
SAP Tradeworld (ED Expert) |
Paul Hills |
|
AEDL (ED Expert) |
Mike Klink |
|
Klop Accelerator (ED Expert) |
Guy Harris |
|
McKellar & Associates (ED Expert) |
Ralp McKellar |
|
SAGE WIZE (ED Expert) |
Jean Van Der Merwer |
NW1257E
04 October 2016 - NW1124
Kruger, Mr HC to ask the Minister of Small Business Development
(1)How many jobs did her (a) department and (b) the agencies reporting to her directly create in the South African economy in the (i) 2014-15 and (ii) 2015-16 financial years;
Reply:
(1) How many jobs did her (a) department and (b) the agencies reporting to her directly create in the South African economy in the (i) 2014-15 and (ii) 2015-16 financial years;
(a) Jobs supported through Department Incentives Programs
Program |
Number of Jobs Supported |
Total |
|
2014-15 |
2015-16 |
||
Corporative Incentive Scheme ( CIS) |
1359 |
1542 |
2901 |
Secondary Marketing Corporative Incentive Scheme ( SMCIS) |
330 |
330 |
|
Black Business Supplier Development Program (BBSDP) |
10425 |
11217 |
21642 |
(b) Jobs supported by agencies
Program |
Number of jobs supported |
Total |
||
2014-15 |
2015-16 |
|||
SEDA Provincial Network |
2099 |
2696 |
4795 |
|
Incubation Programme |
Permanent jobs |
2035 |
2331 |
4366 |
Temporary jobs |
1283 |
1055 |
2338 |
|
Sefa ( created and sustained) |
60 169 |
157 417 |
217 586 |
|
Grand Estimated Total |
253 958 |
(2) What mechanisms are in place to ensure that a job that has been created is sustained beyond the year in which it was created;
For the department the employment figures are captured during receipt of an application and approval stage and are verified when the clients are being interviewed by the staff. This process is conducted when the unit performs site visits to verifiy the existance of the business, interviewing the clients about the interventions applied for and as well as the content of the information as captured in the application forms.
Sefa’s funding to repeat clients has gained traction in recent years, both among its direct lending and wholesale lending clients (the latter being financed through the micro finance institutions (MFIs) and retail finance institutions (RFIs). To this end, each year, sefa captures information on both new jobs as well as jobs maintained as a result of their repeat clients.
Seda provincial network uses the client journey approach whereby clients receive more than one intervention over an agreed period of support which results in a greater impact on the growth and development of a business. To track the progress and impact after completion of an intervention, Seda conducts an improvement assessment. The business incubation programme is supportive of SMMEs by design and as such SMMEs in the programme are nurtured to continue to grow and hence sustain the jobs created.
(3) What were the gross tax revenues raised and gross addition to South Africa’s Gross Domestic Product directly resulting from the creation of these jobs?
For the Seda Provincial Network, out of a sample size of 841 improvement assessments for the 2014/2015; the clients realised a combined increase in turnover of R230 888 275,00. This sample is from a population of 10,697 clients that were assisted during the financial year.
Out of a sample size of 909 improvement assessments for the 2015/2016; the clients realised a combined increase in turnover of R398 531 287, 30. This sample is from a population of 10,679 clients that were assisted during the financial year.
For the Seda Incubation Programme, for the 2015/16 financial year, the incubation programme recorded a total turn over for the 1 650 supported SMMEs of R 605 908 829
For 2014/15 FY, the SMMEs supported under incubation programme generated a total of R488 980 979.
The department and sefa does not have information pertaining to its client’s tax revenues
NW1258E
04 October 2016 - NW2079
Kalyan, Ms SV to ask the Minister in The Presidency: Women
(1)Whether each Head of Department (HOD) of her department signed a performance agreement since their appointment; if not, (a) what is the total number of HODs who have not signed performance agreements, (b) what is the reason in each case, (c) what action has she taken to rectify the situation and (d) what consequences will the specified HOD face for failing to sign the performance agreements; if so, (i) when was the last performance assessment of each HOD conducted and (ii) what were the results in each case; (2) whether any of the HODs who failed to sign a performance agreement received a performance bonus since their appointment; if not, what is the position in this regard; if so, (a) at what rate and (b) what criteria were used to determine the specified rate; (3) whether any of the HODs who signed a performance agreement received a performance bonus since their appointment; if so, (a) at what rate and (b) what criteria were used to determine the rate?
Reply:
- Yes
- Not applicable.
- Not applicable
________________________
Approved by the Minister on
Date………………………..
03 October 2016 - NW1740
Van der Westhuizen, Mr AP to ask the Minister of Public Service and Administration
With reference to the Minister of Finance’s Budget Speech on 24 February 2016, in which the Minister announced the Government’s intention to cut R25 billion over three years from the Governments’ wage bill, (a) how does the total wage bill for the first four months of the 2016-17 financial year compare to that of the first four months of the 2015-16 financial year, (b) what has been the total wage bill of government in the (i) 2014-15 and (ii) 2015-16 financial years, (c) what savings in the wage bill have been achieved due to austerity measures over the first four months of the 2016-17 financial year, (d) is the Government still on track in achieving its target of R25 billion in wage bill savings over the next two financial years and (e) what percentage of the total government expenditure was allocated to wages in the (i) 1996-97, (ii) 2006-07 and (iii) 2016-17 financial years?
Reply:
With reference to the Minister of Finance's Budget Speech on 24 February 2016, in which the Minister announced Government's intention to cut R25 billion over three years from the Public Service (national and provincial government) wage bill,
(a) According to information received from National Treasury, the first four months of the 2016-17 financial year compared to that of the first four months of the 2015-16 financial year, is as reflected in the Table below;
R'000 |
April |
May |
June |
July |
Total |
||||||||||
2015/16 |
32 |
125 |
538 |
32 |
547 |
131 |
37 |
501 |
783 |
34 |
217 |
531 |
136 |
391 |
983 |
2016/17 |
37 |
255 |
422 |
37 |
898 |
664 |
38 |
512 |
932 |
38 |
314 |
848 |
151 |
981 |
865 |
(b) The Public Service wage bill in the following financial years:
(i) 2014-15
Amounts to total consolidated expenditure' of R396 888.1 million.
(ii) 2015-16
Amounts to total consolidated expenditure2 of R430 547.8 million (revised Estimate).
(c) What savings in the wage bill have been achieved due to austerity measures over the first four months of the 2016-17 financial year?
While earnings of public servants have increased during the first four months of 2016/17 financial year, departments have managed to contain headcount growth over the same period. Headcount has reduced by 0.6 per cent across the board for national and provincial spheres of government. In financial terms, this amounts to R2.8 billion in projected savings for the whole financial year
(d) Is the Government still on track in achieving its target of R25 billion in Public
Service wage bill savings over the next two financial years?
Government is committed to spending within set compensation budget ceilings and will continue to enforce them over the next two financial years. Indications are that set targets will be achieved as planned.
(e) What percentage of the total government expenditure was allocated to Public Service wages in the following financial years -
(i) 1996-97
The percentage of the total government expenditure allocated to wages is 40.8%3
(ii) 2006-07
The percentage of the total government expenditure allocated to wages is 31.3%4
(iii) 2016-17
The percentage of the total government expenditure allocated to wages is 33.6%.5
03 October 2016 - NW2066
Horn, Mr W to ask the Minister of Public Service and Administration
(1)Whether each Head of Department (HOD) of his department signed a performance agreement since their appointment; if not, (a) what is the total number of HODs who have not signed performance agreements, (b) what is the reason in each case, (c) what action has he taken to rectify the situation and (d) what consequences will the specified HOD face for failing to sign the performance agreements; if so, (i) when was the last performance assessment of each HOD conducted and (ii) what were the results in each case; (2) whether any of the HODs who failed to sign a performance agreement received a performance bonus since their appointment; if not, what is the position in this regard; if so, (a) at what rate and (b) what criteria were used to determine the specified rate; (3) whether any of the HODs who signed a performance agreement received a performance bonus since their appointment; if so, (a) at what rate and (b) what criteria were used to determine the rate?
Reply:
(1) Yes.
a) None.
b) Falls Away.
c) Not applicable.
d) Falls away, (i) and (ii) please refer to the table herewith below;
Name |
(ii) |
|
Department of Public Service and Administration |
2014/2015 |
Fully effective |
Office of the Public Service Commission |
None, the HOD was appointed on 1 June 2016 |
Falls away |
National School of Government |
2014/2015 |
Eligible for pay progression |
Centre for Public Service Innovation |
2015/2016 |
Outstanding performance rating |
(2) None.
(3) None.
03 October 2016 - NW2031
Brauteseth, Mr TJ to ask the Minister of Public Service and Administration
What formal qualifications does each of his department’s (a)(i) Chief Financial Officers and/or (ii) acting Chief Financial Officers and (b)(i) Directors-General and/or (ii) acting Directors-General possess?
Reply:
(a) (i) The Chief Financial Officer of the Department of Public Service and
Administration possesses the following formal qualifications;
- Matric Certificate
- Bachelor of Arts in Education
- Master of Education
- Master of Management Public and Development Management
(ii) The Department of Public Service and Administration does not have acting Chief Financial Officer
(b) (i) The Director-General of the Department of Public Service and Administration
possesses the following formal qualifications;
- Matric Certificate
- Bachelor of Commerce
- Certificate Programme in Finance and Accounting (CPFA)
- Programme and Project Management in Public and Management
(ii) The Department of Public Service and Administration does not have acting Director-General
03 October 2016 - NW1653
Van der Westhuizen, Mr AP to ask the Minister of Public Service and Administration
What (a) is the job description of his department’s ethics officer and (b) are the critical performance indicators for the specified position?
Reply:
(a) The Department of Public Service and Administration does not have a dedicated official performing the functions of an Ethics Officer. However it has assigned an official in the Office of the Director-General to perform key ethics officer functions in addition to her other duties. In this regard her role entails the following:
- Liaison with all members of the SMS regarding the submission of Financial Disclosures.
- Initial scrutiny of all submitted disclosures to assess if they are complete.
- Follow-up with relevant managers whose disclosures might be incomplete.
- Forwarding of all completed disclosures to the Executive Authority for onward processing to the Public Service Commission.
- Brief report to the Director-General on the disclosure process and the results thereof.
(b) The critical performance indicators are:
- Timely and complete disclosure of financial interests by SMS members; and
- Timely advice to the Accounting Officer regarding non-compliant officials for purposes of follow-up and where necessary, disciplinary action.
03 October 2016 - NW1753
Mulder, Dr PW to ask the Minister of Public Service and Administration
Whether his department has met the requirements of the Use of Official Languages Act, Act No 12 of 2012, according to which his department (a) has established an official language policy for the department and (b) instituted a language unit; if not, (i) why not and (ii) what steps he will take to ensure that the provisions of the Act are met; if so, what are the relevant particulars?
Reply:
(a) The DPSA has developed an Official Language Policy which has been submitted to the Government Printing Works for publication in the Government Gazette for public comment. The Notice was published in Government Gazette of 23 September 2016 (No. 40293 23-9 Notice No. 1081) which is available on the GPW website: www.qpwonline.co.za All interested persons and organisations who would like to submit written comments are provided with 30 days to do so from the day of publication in the Government Gazette. The Policy is available on the DPSA website: www.dosa.qov.za
(b) The process of having an operational Language Unit is under consideration at the moment and will be concluded once the Official Language Policy has been finalised.
30 September 2016 - NW1890
Lotriet, Prof A to ask the Minister of Science and Technology
Whether any investigations have been launched by (a) her department and/or (b) the Technology Innovation Agency into the sale of the specified agency’s 49% shareholding in Kapa Biosystems to American shareholders for U$ 4.93 million, which was subsequently sold to a certain company (name furnished) for an alleged amount of U$ 445 million; if not, why not; if so (i) who conducted the investigation, (ii) what were the findings, (iii) will the findings be made available and (iv) by what date?”
Reply:
(a) The Minister established a task team to determine the facts of the matter and the most appropriate course of action.
- The Task Team is still determining the facts of the matter and the most appropriate course of action.
- There are currently no findings as the Task Team is still verifying the veracity of the allegations made.
- The Minister will advise Cabinet on the outcome of the assessment conducted by the Task Team.
- The date cannot be ascertained at this stage as the assessment is still ongoing.
9/1/4/5/2/A/2
THE MINISTER
QUESTION 1890 FOR WRITTEN REPLY: NATIONAL ASSEMBLY: DR A LOTRIET (DA): SALE OF TIA’S SHAREHOLDING IN KAPA BIOSYSTEMS TO AMERICAN SHAREHOLDERS
INTRODUCTION
- The above-mentioned question appears on the Internal Question Paper No. 28 dated 16 September 2016 for written reply in the National Assembly.
2. A draft reply to the question is enclosed in Pocket 2 for the Minister’s consideration.
Recommendations
3. It is recommended that the Minister approves the draft reply enclosed in Pocket 2 if the Minister concurs with its contents.
DIRECTOR-GENERAL
DATE:
QUESTION 1890 FOR WRITTEN REPLY: NATIONAL ASSEMBLY: DR A LOTRIET (DA): SALE OF TIA’S SHAREHOLDING IN KAPA BIOSYSTEMS TO AMERICAN SHAREHOLDERS
DECISION
Reply approved/not approved.
Further discussion required/not required.
Proposed date for discussion:
MINISTER OF SCIENCE AND TECHNOLOGY
DATE:
9/1/4/5/2/A/2
THE DEPUTY MINISTER
QUESTION 1890 FOR WRITTEN REPLY: NATIONAL ASSEMBLY: DR A LOTRIET (DA): SALE OF TIA’S SHAREHOLDING IN KAPA BIOSYSTEMS TO AMERICAN SHAREHOLDERS
Enclosed in Pocket 1, please find a copy of a submission to the Minister for your information.
DIRECTOR-GENERAL
DATE:
DECISION
Contents noted.
Further discussion required/not required.
Proposed date for discussion: ………………………………………….
DEPUTY MINISTER OF SCIENCE AND TECHNOLOGY
DATE:
ROUTE FORM
SUBMISSION TO THE MINISTER OF SCIENCE AND TECHNOLOGY
PROGRAMME |
2 |
FILE NO. |
9/1/4/5/2/A/2 |
SUBJECT |
QUESTION 1890 FOR WRITTEN REPLY: NATIONAL ASSEMBLY: DR A LOTRIET (DA): SALE OF TIA’S SHAREHOLDING IN KAPA BIOSYSTEMS TO AMERICAN SHAREHOLDERS |
ABBREVIATED DESIGNATION SURNAME AND INITIALS |
ELECTRONIC SIGNATURE |
COMMENTS |
B Durham CD: Bio |
M Muofhe DDG: TI |
30 September 2016 - NW2041
Steenkamp, Ms J to ask the Minister of Trade and Industry
What formal qualifications does each of his department’s (a)(i) Chief Financial Officers and/or (ii) acting Chief Financial Officers and (b)(i) Directors-General and/or (ii) acting Directors-General possess?
Reply:
(a)(i) Chief Financial Officer
The qualifications for the Chief Financial Officer are Bachelor of Commerce and Honours Bachelor of Accounting Science.
(a)(ii) acting Chief Financial Officer
There is currently no acting CFO within the Department
(b)(i) Directors-General
The qualifications for the Director-General are Baccalaureus Lurisprudenciae, Honours Baccalaureus Artium Degree and Master’s Degree in Economics.
(b)(ii) acting Directors-General
There is currently no acting Director-General within the Department
30 September 2016 - NW2111
Matsepe, Mr CD to ask the Minister of Trade and Industry
What amount did (a) his department and (b) each entity reporting to him spend on advertising on the (i) Africa News Network 7 channel, (ii) SA Broadcasting Corporation (aa) television channels and (bb) radio stations, (iii) national commercial radio stations and (iv) community (aa) television and (bb) radio stations (aaa) in the 2015-16 financial year and (bbb) since 1 April 2016?
Reply:
(i) (aa) (bb) (aaa) (bbb)
No spending was recorded in the department on advertising with the Africa News Network Channel or with the South African Broadcasting Corporation’s television channels in the 2015-16 financial year and from 1 April 2016 to date.
(ii) (bb) (aaa) (bbb)
The spending on advertising with the South African Broadcasting Corporation’s radio stations was R511 382.91 in the 2015-16 financial year and R659 226 from 1 April 2016 to date related to key areas of the dti’s work programme.
(iii) (aa) (bb) (aaa) (bbb)
No spending was recorded in the department on advertising with the national commercial radio stations, television channels and community television channels in the 2015-16 financial year and from 1 April 2016 to date.
(iv) (bb) (aaa) (bbb)
The spending on advertising on community radio stations for the 2015-16 financial year was R388 787 and R1 772 419.33 from 1 April 2016 to date on advertising campaigns.
Response from the Entities
ENTITY |
QUESTIONS |
RESPONSES |
|
NLC |
(i) Africa News Network 7 channel |
- |
|
(ii) SA Broadcasting Corporation |
(aaa) 2015-16 fy |
(bbb) |
|
(aa) television channels |
R900 000.00 |
R1 193 607.36 |
|
(bb) radio stations |
R6076288.60 |
R887583.07 |
|
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
R994790.00 |
R117 655.00 |
|
NEF |
(i) Africa News Network 7 channel |
- |
|
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
||
(bb) radio stations |
- |
||
(iii) national commercial radio stations |
R901 867.68 |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
R28 096.50 |
R7 200.00 |
|
ECIC |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
(aaa) |
(bbb) |
|
(aa) television channels |
- |
- |
|
(bb) radio stations |
R78 156.00 |
R52 104.00 |
|
(iii) national commercial radio stations |
R333 606.00 |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
|
SABS |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
||
(bb) radio stations |
- |
||
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
|
NGB |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
||
(bb) radio stations |
- |
||
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
R141,684.90 |
|
NCT |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
(aaa) |
(bbb) |
|
(aa) television channels |
- |
- |
|
(bb) radio stations |
- |
- |
|
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
|
SANAS |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
||
(bb) radio stations |
- |
||
(iii) national commercial radio stations and |
R37 962.00 |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
|
NRCS |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
||
(bb) radio stations |
R472 701.00 |
||
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
|
CT |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
||
(bb) radio stations |
- |
||
(iii) national commercial radio stations |
R122 586.07 |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
|
NCC |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
R2 110 719.48 |
||
(bb) radio stations |
R1 513 511.26 |
||
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
|
CIPC |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
- |
|
(bb) radio stations |
- |
- |
|
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
R463 879.68 |
- |
|
(bb) radio stations |
- |
- |
|
NCR |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
- |
|
(bb) radio stations |
- |
- |
|
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
R33 610.00 |
R502 321.88 |
|
NMISA |
(i) Africa News Network 7 channel |
(aaa) |
(bbb) |
- |
- |
||
(ii) SA Broadcasting Corporation |
|||
(aa) television channels |
- |
- |
|
(bb) radio stations |
- |
- |
|
(iii) national commercial radio stations |
- |
||
(iv) community |
(aaa) 2015-16 fy |
(bbb) since 1 April 2016 |
|
(aa) television |
- |
- |
|
(bb) radio stations |
- |
- |
30 September 2016 - NW2104
Malatsi, Mr MS to ask the Minister of Science and Technology
(a) What amount did (a) her department and (b) each entity reporting to her spend on advertising on the (i)Africa News Network 7 channel, (ii) SA Broadcasting Corporation (aa)television channels and (bb) radio stations, (iii) national commercial radio stations and (iv) community (aa) television and (bb) radio stations (aaa) in the 2015-16 financial year and (bbb)since April 2016?"
Reply:
(a) The Department of Science and Technology spentthe following on advertising (aaa) in the 2015/16 financial year, and (bbb) since 1 April 2016:
(i) Africa News Network 7 channel
(aaa) |
(bbb) |
R369 344,00 |
R613 670,40 |
(ii)(aa) South African Broadcasting Corporation television channels
(aaa) |
(bbb) |
R1 798 668, 01 |
R400 088,00 |
(ii)(bb) South African Broadcasting Corporation radiostations
(aaa) |
(bbb) |
R1 884 310,00 |
R410 000,00 |
(iii) National commercial radio stations
(aaa) |
(bbb) |
R878 692,88 |
R273 200,00 |
(iv)(aa) Community television
(aaa) |
(bbb) |
R1 368 000,00 |
Nil |
(iv)(bb) Community radio stations
(aaa) |
(bbb) |
R238 790,00 |
Nil |
(b) The entities reporting to the Minister of Science and Technology spent the following on advertising:
(i) Africa News Network 7 channel
Entity |
(aaa) |
(bbb) |
Academy of Science of South Africa |
Nil |
Nil |
Council for Scientific and Industrial Research |
Nil |
Nil |
Human Sciences Research Council |
Nil |
Nil |
National Research Foundation |
Nil |
Nil |
South African National Space Agency |
Nil |
Nil |
Technology Innovation Agency |
Nil |
Nil |
(ii)(aa) South African Broadcasting Corporation television channels
Entity |
(aaa) |
(bbb) |
Academy of Science of South Africa |
Nil |
Nil |
Council for Scientific and Industrial Research |
R2 677 725,00 |
Nil |
Human Sciences Research Council |
R7 296,00 |
Nil |
National Research Foundation |
Nil |
Nil |
South African National Space Agency |
Nil |
Nil |
Technology Innovation Agency |
Nil |
Nil |
(ii)(bb) South African Broadcasting Corporation radiostations
Entity |
(aaa) |
(bbb) |
Academy of Science of South Africa |
Nil |
Nil |
Council for Scientific and Industrial Research |
R450 000,00 |
Nil |
Human Sciences Research Council |
Nil |
Nil |
National Research Foundation |
R200 000,00 |
Nil |
South African National Space Agency |
Nil |
Nil |
Technology Innovation Agency |
Nil |
Nil |
(iii) National commercial radio stations
Entity |
(aaa) |
(bbb) |
Academy of Science of South Africa |
Nil |
Nil |
Council for Scientific and Industrial Research |
Nil |
Nil |
Human Sciences Research Council |
Nil |
Nil |
National Research Foundation |
Nil |
Nil |
South African National Space Agency |
Nil |
Nil |
Technology Innovation Agency |
Nil |
Nil |
(iv)(aa) Community television
Entity |
(aaa) |
(bbb) |
Academy of Science of South Africa |
Nil |
Nil |
Council for Scientific and Industrial Research |
Nil |
Nil |
Human Sciences Research Council |
Nil |
Nil |
National Research Foundation |
Nil |
Nil |
South African National Space Agency |
Nil |
Nil |
Technology Innovation Agency |
Nil |
Nil |
(iv)(bb) Community radio stations
Entity |
(aaa) |
(bbb) |
Academy of Science of South Africa |
Nil |
Nil |
Council for Scientific and Industrial Research |
R256 000,00 |
R110 000,00 |
Human Sciences Research Council |
Nil |
Nil |
National Research Foundation |
Nil |
R14 711,80 |
South African National Space Agency |
R12 030,00 |
R25 720,00 |
Technology Innovation Agency |
Nil |
Nil |
29 September 2016 - NW2040
Steenkamp, Ms J to ask the Minister of Tourism
What formal qualifications does each of his department’s (a) (i) Chief Financial Officers and/or (ii) acting Chief Financial Officers and (b) (i) Directors-General and/or (ii) acting Directors-General possess?
Reply:
a) (i) Chief Financial Officer
National Diploma: State Accounts and Finance
(ii) Acting Chief Financial Officers
Not applicable
(b)(i) Directors-General
Bachelor of Science Degree in Physics and Applied Physics
International Graduate Diploma in Environmental Management (Israel)
Postgraduate Diploma in Strategic Management and Corporate Governance
Graduate Diploma in Company Direction
(ii) Acting Directors-General
Not applicable
29 September 2016 - NW2042
Figg, Mr MJ to ask the Minister of Transport
What formal qualifications does each of her department’s (a)(i) Chief Financial Officers and/or (ii) acting Chief Financial Officers and (b)(i) Directors-General and/or (ii) acting Directors-General possess?
Reply:
What formal qualifications does each of her department’s (a)(i) Chief Financial Officers and/or (ii) acting Chief Financial Officers and (b)(i) Directors-General and/or (ii) acting Directors-General possess?
The formal qualifications of the:
(a)(i) Financial Officer;
(a)(ii) Acting Chief Financial Officer;
(b)(i) Director-General; and
(b)(ii) Acting Director-General
are as follows:
QUESTION |
POST |
QUALIFICATIONS |
(a)(i) |
Chief Financial Officer |
Grade 12 B Comm Degree Diploma in Central Banking Diploma in Treasury Management & Trade Finance Advanced Diploma in Central Banking Certified Associate of the IOB International Capital Market Qualification |
(a)(ii) |
Acting Chief Financial Officer |
Grade 12 B Comm Degree B Comm Honours Degree in Accounting |
(b)(i) |
Director-General: Transport |
Position vacant |
(b)(ii) |
Acting Director-General: Transport |
Grade 12 Diploma in Public Administration Bachelor of Arts Degree Post Graduate Diploma in Transport Management Master of Business Administration Degree |
29 September 2016 - NW1904
Majola, Mr TR to ask the Minister of Tourism
Why has the SA National Convention Bureau not tabled its quarterly breakdown of the 138 meetings scheduled for the 2016-17 financial year, as committed to in the presentation made by SA Tourism to the Portfolio Committee on Tourism on 8 April 2016?
Reply:
The SA National Convention Bureau provided a report to the Portfolio Committee as Annexure A1 of the SA Tourism Quarter 1 presentation to the Portfolio Committee, for the meeting of 2 September 2016. The document was distributed on 29 August 2016 to the committee secretariat.
29 September 2016 - NW1927
Terblanche, Ms JF to ask the Minister of Transport
(1)Whether, with reference to her reply to question 164 on 29 February 2016, any further motor vehicle license renewal notices have not reached motorists on time; if not, what is the position in this regard; if so, (a) why and (b) why are the specified motorists being penalised for not renewing the specified licenses on time; (2) whether she is considering an alternative method of issuing the motor vehicle license renewal notices in the future; if not, why not; if so, what are the relevant details?
Reply:
(1) (a) From the information that the Department has received we have been advised that the renewal notices are being sent to all the motorist.
(b) In terms the legislation it required that a motor vehicle be licensed after every twelve months, therefore it is the responsibility of the owners of a motor vehicles to renew their licenses after the expiry thereof.
(2) At this stage the Department have not yet engaged with all the role players , however we will be engaging on finding ways of using technology to improve the service delivery.
29 September 2016 - NW1926
Stander, Ms T to ask the Minister of Transport
What (a) were the objectives of the Youth Road Safety Summit launched on 25 June 2016 in Pretoria, Gauteng, (b) was achieve, measured against the specified objectives, (c) are the timeframes for the specified objectives and (d) mechanisms have been put in place to ensure that the specified objectives are met?
Reply:
(a) The Youth Road Safety Summit that was held on 25 June was a culmination of Provincial Road Safety Youth Summits that were held in all provinces. The purpose was to establish a National Structure of young people who are engaged in road safety. The aim is to place youth at the centre of finding solutions to the ever daunting task of road deaths as these affect the youth more than any age category of road users.
(b) A National Structure was established. It is made up of the youth from all provinces and different organisations ranging from businesses, NGOs, (b) faith-based organisations, etc. These were also co-opted into the structure.
(c) The term of office of the elected body is one year. They have the responsibility of developing a programme that will focus on youth and road safety. In developing such a programme, they will take into account what is being done in the fraternity and what the shortcomings area as well as coming up with innovative ways of appealing to the youth. The programmes have to be all inclusive and accomodative of divergent youth of the country.
(d) The RTMC has been mandated to provide support to the national structure, with other road entities interacting with the structure as well. The provinces are expected to play a similar role with regards to supporting the youth structures in respective provinces.
29 September 2016 - NW1911
Mokgalapa, Mr S to ask the Minister of Tourism
(a) What are the causes for the delays in the transfer of R2,9 million from his department to SA Tourism and (b) how often did SA Tourism not receive funds allocated by his department as per the agreed time frames?
Reply:
(a) There was no delay in the transfer of funds to South African Tourism. The total marketing allocation as appropriated was transferred in April 2016 upon National Treasury’s approval, to allow for management of potential currency losses.
(b) Not applicable. The department transfers the contribution to South African Tourism quarterly in advance.
29 September 2016 - NW1903
Vos, Mr J to ask the Minister of Tourism
Whether SA Tourism has conducted any studies to determine why the accommodation industry, especially hotels, are cancelling their membership to the specified entity’s grading schemes; if not, why not; if so, what (a) are the relevant details and (b) steps are being taken to curb this trend?
Reply:
No, SA Tourism has not conducted any studies to determine why the accommodation industry. The Tourism Grading Council of South Africa (TGCSA) will be conducting formal research in quarter three of 2016/17, to determine the perceptions of grading in the sector which will provide insight into the reasons for cancellations.
(a) The results of this research study will assist the TGCSA greatly in its strategy development and implementation.
(b) In order the address the cancellations, the TGCSA is currently implementing the following
measures and actions:
(i) TGCSA is working closely with NDT to address the cost of grading through the Grading Support Programme offered by the Tourism Incentive Programme (TIP).
(ii) TGCSA’s Basket of Benefits continues to be developed and updated to ensure the business support services and discounts available on the platform are relevant to all categories. Registration of establishments on the Basket of Benefits platform continues to grow.
(iii) TGCSA has opted to implement Memoranda of Understanding (MOU) with Provincial Consumer Protection Authorities directly. The basis of these memoranda is to partner with and enlist the services and support of the provincial bodies to eradicate the illegal usage of stars in the provinces through consumer and trade education initiatives. MOUs have either been concluded or are in the final stages of conclusion between TGCSA and the Western Cape, Eastern Cape, Gauteng and Kwazulu-Natal authorities. The remaining provinces are currently at consultation phase. TGCSA has also presented the consumer impact of the illegal usage of stars at the National Consumer Forum.
(iv) TGCSA has provided input to Treasury on the amendments to the National Travel Policy. This policy and pending revisions have been closely linked to star grading and will encourage grading amongst establishments as well as direct government procurement of travel services.
29 September 2016 - NW1919
Motau, Mr SC to ask the Minister of Transport
With reference to her reply to question 405 on 8 March 2016, (a) who are the members of the Traffic Legislation Technical Committee, (b) what criteria were used to appoint the members to the committee and (c) why have certain members serving previously on the committee been excluded?
Reply:
(a) The members of the TLTC are the National Department of Transport together with its Agencies and the 9 Provincial Departments responsible for transport.
(b) Road Traffic Regulation is a functional areas of concurrent National and Provincial legislative competence as provided for in terms of schedule 4 of the Constitution, so each province must form part of this committee for decision making.
(c) There are no members that have been excluded.
29 September 2016 - NW1909
Mhlongo, Mr TW to ask the Minister of Tourism
(1)(a) What is the current status of the process to appoint a chief executive officer for SA Tourism and (b) by what date will the specified position be filled; (b) by what date will the specified position be filled; (2) what amount did SA Tourism spend on the remuneration of board members in the (a) 2013-14, (b) 2014-15 and (c) 2015-16 financial years; (3) (a) what are the details of the current vacancy rate at SA Tourism and (b) how do the specified vacancies affect the performance of SA Tourism, especially relating to marketing activities?
Reply:
1. (a) Following Cabinet’s concurrence on 28 September 2016, the recommended candidate, Mr Sisa Ntshona was notified of his appointment as CEO by the SA Tourism Board.
(b) Mr Ntshona will assume duties on 3 October 2016.
2. (a) Remuneration of Board members was tabled in the SA Tourism Annual Report 2013/14. Refer to page 73 and 100.
(b) Remuneration of Board members was tabled in the SA Tourism Annual Report 2014/15. Refer to page 74 and 75.
(c) Remuneration of Board members was tabled in the SA Tourism Annual Report 2015/16. Refer to page 81 and 82.
3. (a) SA Tourism Vacancies:
Business Unit |
Approved positions |
Occupied positions |
Vacant positions |
Temporary staff |
Office of the CEO |
6 |
5 |
1 |
- |
Operations |
30 |
28 |
2 |
2 |
Finance |
23 |
22 |
1 |
3 |
SANCB |
15 |
12 |
3 |
2 |
Marketing |
114 |
93 |
21 |
4 |
TGCSA |
14 |
14 |
- |
- |
Total |
202 |
174 |
28 |
11 |
(b) The vacancies have not affected the performance of SA Tourism. Interim arrangements have been made to ensure that the operations of the organisation are not impacted during the organisational review process.
29 September 2016 - NW2110
Masango, Ms B to ask the Minister of Tourism
What amount did (a) his department and (b) each entity reporting to him spend on advertising on the (i) Africa News Network 7 channel, (ii) SA Broadcasting Corporation (aa) television channels and (bb) radio stations, (iii) national commercial radio stations and (iv) community (aa) television and (bb) radio stations (aaa) in the 2015-16 financial year and (bbb) since 1 April 2016?
Reply:
(a) Department of Tourism spend on
Media |
Media |
(aaa) 2015-16 Financial year |
(bbb) Since 1 April 2016 |
|
- |
0 |
0 |
(ii) SABC |
(aa) Television channels |
0 |
0 |
(bb) Radio Stations |
0 |
0 |
|
(iii) National Commercial radio stations |
- |
0 |
0 |
(iv) Community |
(aa) Community television |
0 |
0 |
(bb) radio stations |
0 |
0 |
(b) SA Tourism spend on
Media |
Media |
(aaa) 2015-16 Financial year |
(bbb) Since 1 April 2016 |
(i)ANN 7 |
- |
N/A |
N/A |
(ii) SABC |
(aa) Television channels |
R21,500,000 |
R2,072,300 |
(bb) Radio Stations |
R1,395,030 |
R7,299,932.86 |
|
(iii) National Commercial radio stations |
- |
R5,204,575.50 |
R2,698,224.19 |
(iv) Community |
(aa) Community television |
N/A |
N/A |
(bb) radio stations |
R1,200,000.00 |
N/A |
29 September 2016 - NW2077
Kalyan, Ms SV to ask the Minister of Transport
(1)Whether each Head of Department (HOD) of her department signed a performance agreement since their appointment; if not, (a) what is the total number of HODs who have not signed performance agreements, (b) what is the reason in each case, (c) what action has she taken to rectify the situation and (d) what consequences will the specified HOD face for failing to sign the performance agreements; if so, (i) when was the last performance assessment of each HOD conducted and (ii) what were the results in each case; (2) whether any of the HODs who failed to sign a performance agreement received a performance bonus since their appointment; if not, what is the position in this regard; if so, (a) at what rate and (b) what criteria were used to determine the specified rate; (3) whether any of the HODs who signed a performance agreement received a performance bonus since their appointment; if so, (a) at what rate and (b) what criteria were used to determine the
Reply:
1. In response to the above-mentioned questions, it should be mentioned that the last permanent HOD left the Department in February 2013. From 2013/14 to 2014/15, i.e. for these two financial years, the Department did not have a permanent HOD, except several tenures of acting appointments.
The next permanent HOD, Mr PG Selepe, was appointed on 25 February 2015 (i.e. one month before the end of the 2014/15 performance cycle).
Mr PG Selepe has signed his Performance Agreement for 2015/16 on 30 June 2015 instead of 31 May, the Performance Agreement was submitted to the Public Service Commission on 30 June 2015 as a requirement for all the permanent HODs.
(a) For 2016/17, Mr PG Selepe did not sign the Performance Agreement by 31 May 2016.
(b) Mr PG Selepe was put on special leave with effect from 3 May 2016 until to date (i.e. few weeks before the due date of 31 May 2016).
(c) Not applicable, due to response in (b).
(d) A consequence for not signing Performance Agreement will result in forfeiture of performance incentives including pay progression for the 2015/16 performance cycle in line with the DPSA directive of 31/07/2012. In this case it will not be applicable due to response in (b).
(1)(i) The then HOD, Mr PG Selepe, did not comply in submitting the 2015/16 Half Yearly Review and 2015/16 Annual Performance Assessment.
(1)(ii) In view of the above, this is not applicable.
(2) For the past two consecutive performance cycles (i.e. 2013/14 and 2014/15), there was no HOD, hence there was no reporting. Therefore a response to this question is not applicable.
(3) Not applicable due to the reasons given above.
29 September 2016 - NW2034
Cassim, Mr Y to ask the Minister of Science and Technology
What formal qualifications does each of her department’s (a)(i) Chief Financial Officers and/or (ii) acting Chief Financial Officers and (b)(i) Directors-General and/or (ii) acting Directors-General possesses?”
Reply:
(a)(i) The Chief Financial Officer position is permanently filled. The employee has the following qualifications:
- Bachelor of Commerce.
- Master’s Degree in Business Administration.
(a)(ii) Not applicable. The position is permanently filled.
(b)(i) The Director-General position is permanently filled. The employee has the following qualifications:
- Bachelor of Science Degree.
- Bachelor of Science Honours Degree.
- Master of Science Degree.
- Doctor of Philosophy.
(b)(ii) Not applicable. The position is permanently filled.
29 September 2016 - NW2069
Hunsinger, Dr CH to ask the Minister of Science and Technology
(1)Whether each Head of Department (HOD) of her department signed a performance agreement since their appointment; if not, (a) what is the total number of HODs who have not signed performance agreements, (b) what is the reason in each case, (c) what action has she taken to rectify the situation and (d) what consequences will the specified HOD face for failing to sign the performance agreements; if not, (i) when was the last performance assessment of each HOD conducted and (ii) what were the results in each case; (2) whether any of the HODs who failed to sign a performance agreement received a performance bonus since their appointment; if not what is the position in this regard; if so, (a) at what rate and (b) what criteria were used to determine the specified rate; (3) whether any of the HODs who signed a performance agreement received a performance bonus since their appointment; if so, (a) at what rate and (b) what criteria were used to determine the specified rate?”
Reply:
1. The Head of Department (HOD) of Science and Technology has signed a performance agreement annually since his appointment in 1 April 2006.
2. The HOD has consistently signed a performance agreement since his appointment.
3. The HOD received a performance bonus at a percentage rate approved by Public Service Commission in line with his performance assessment result of above average performance.
29 September 2016 - NW1928
Terblanche, Ms JF to ask the Minister of Transport
(a) Why are enatic face value documents unavailable in some provincial department of transport offices, (b) what is being done to ensure that these documents are available in all offices and (c) by what date is this expected to be resolved?
Reply:
(a) Although provinces ordered adequate stock from the Government Printing Works to deal with all the service of all transactions required, the backup stock of face value documents that they keep was not enough to deal with the growth in the number of services that were required.
(b) Provinces have been advised to request assistance from other Registering Authorities that have surplus face value documents. Furthermore, provinces have been advised that in their projections they must ensure that there is enough face value documents.
(c) The matter has been resolved. Government Printing Works has also been advised to order more Face Value documents.
29 September 2016 - NW1907
Mhlongo, Mr TW to ask the Minister of Tourism
Whether his department has achieved its targets of (a) total tourism revenue and (b) job opportunities created up to the latest specified date for which information is available in line with the National Tourism Strategy 2020; if not, in each case, why not; if so, in each case, what are the relevant details?
Reply:
(a) The National Tourism Sector Strategy (NTSS) did not provide an indicator for total tourism revenue. However, targets are provided for Gross Domestic Product (GDP) contribution. In this regard, the targets have been achieved. Tourism was estimated to contribute R71 billion in 2009 in the original NTSS with a target of R118 billion by 2015. The Tourism Satellite Account for South Africa, final 2012 and provisional 2013 and 2014 recorded a contribution of R111 560 billion (2.9% of total GDP) in 2014. In terms of total (direct and indirect) GDP contribution, the World Travel and Tourism Council (WTTC) Travel and Tourism Economic Impact 2016 South Africa Report estimated a contribution of R375 billion in 2015 (9.4% of total GDP).
(b) Yes, 2015 NTSS targets in terms of both direct and total jobs were achieved. The NTSS 2011 provided a baseline of 389 100 direct jobs in 2009 and a target of 403 900 direct jobs in 2015. According to the Tourism Satellite Account for South Africa (final 2012 and provisional 2013 and 2014) tourism contributed 680 817 direct jobs in 2014. The WTTC Travel and Tourism Economic Impact 2016 South Africa Report estimated a contribution of 703 000 direct jobs in 2015. This performance exceeded the National Tourism Sector Strategy targets.
In respect of total jobs (both direct and indirect) contribution, the NTSS set a baseline of 919 800 jobs in 2009 and a target of 968 300 jobs in 2015. The WTTC estimated a total contribution of 1 554 000 jobs in 2015, surpassing the 2020 target of 1 097 000.
29 September 2016 - NW1910
Mokgalapa, Mr S to ask the Minister of Tourism
How has his department allocated the additional R10,7 million received from the tourist levies collected by Tourism Marketing of South Africa?
Reply:
The additional funding of R10,7 million is being used for marketing activities through the Tourism Business Council of SA (TBCSA)/ Tourism Marketing South Africa (TOMSA) and the SA Tourism Collaborative Fund. Four core markets, namely Germany, United States of America, United Kingdom and China have been selected for Joint Marketing Agreements to boost tourist arrivals and tourism revenue into South Africa.
29 September 2016 - NW1908
Mhlongo, Mr TW to ask the Minister of Tourism
Whether he has found that the outcome of the United Kingdom referendum to exit the European Union has had any effects on the number of tourists visiting South Africa from the specified country; if not, why not; if so, what are the relevant details?
Reply:
I have not found that the outcome of the UK referendum has had any effect on tourists’ arrival to South Africa. It is important to note that it would be premature to make any statements on the impact on tourism. Uncertainty around developments in some areas could in the short and medium-term impact on arrivals to South Africa from the UK. It is probable that in the short-term, personal spending will be conservative in anticipation of negative impacts, and that long-haul travel and spending on non-essentials may be conservative.
In the context of arrivals to South Africa, it must be noted that
- June to August are low season months for travel to SA (peak travel months are December-February) and any impact would not be immediately visible.
- The majority of leisure travellers decide on a holiday to SA at least three months before travel. Impact on arrival numbers will only be noted from October 2016 onwards.
28 September 2016 - NW1409
Ross, Mr DC to ask the Minister of Social Development
Whether (a) her department and (b) all entities reporting to her are running development programmes for (i) small businesses and (ii) co-operatives; if not, why not; if so, in each case, (aa) what are the relevant details, (bb) what amount has been budgeted and (cc) how many jobs will be created through the specified development programmes in the 2016-17 financial year?
Reply:
(a) Department of Social Development
- (aa) Not applicable to the department of Social Development
(bb) Not applicable to the department of Social Development
(ii)
(aa) The Department of Social Development facilitates the programme of linking cooperatives to economic opportunities. Cooperatives from poverty stricken wards are identified, profiled and linked to economic opportunities created through the Social Relief of Distress Programme which include supply of vegetables and school uniform to poor and vulnerable families and children. These cooperatives are also linked to economic opportunities created through the Household Food and Nutrition Programme and they supply Community Nutrition and Development Centres with food products and uniform.
(bb) There is no dedicated budget for Cooperatives. Those cooperatives with capacity building needs are referred to the National Development Agency and the Department of Small Business Development and Cooperatives for support.
(cc) not applicable to department of Social Development
SASSA
- SASSA is not running any development programmes for small businesses
(aa) Not applicable to SASSA
(bb) Not applicable to SASSA
(ii)
(aa) SASSA is not running development programmes for co-operatives. However, SASSA utilizes co-operatives for procurement.
The co-operatives are identified and assessed by the Co-operatives Unit
in the Department of Social Development.
Those co-operatives which require development are identified and assisted through the Department of Social Development and the National Development Agency. Once these have met the requirements to register on the Central Supplier database, then SASSA is able to utilize them for procurement of various services, such as social relief of distress, school uniforms, SASSA uniforms and catering, amongst others.
(bb) No dedicated budget for only cooperatives
(cc) Not applicable to SASSA
NDA
The NDA mandate is derived from the National Development Agency Act, (Act No. 108 of 1998). In terms of the act, the primary objective of the NDA is to contribute towards the eradication of poverty.
(i) Small business – the NDA has not supported small business as this function is outside its mandate of supporting Civil Society Organisations.
(aa) Not applicable to NDA
(bb) Not applicable to NDA
(ii)
(aaa) NDA support cooperatives through its capacity building programme as part of its CSOs capacity strengthening interventions. The NDA provides training, mentoring and incubation for CSOs including cooperatives on governance, financial management, conflict management, registration of NPOs and cooperatives. The NDA has planned to capacitate 4950 of CSOs including cooperatives in the 2016/17 financial.
(bbb) The NDA has budgeted R41 147 484.00 for CSOs including cooperatives capacity building interventions in the 2016/17 financial year.
(cc) Not applicable to SASSA
28 September 2016 - NW856
Sonti, Ms NP to ask the Minister of Social Development
(a) How many nongovernmental organisations (NGOs) in each province have been subsidised by her department in 2014 and 2015, (b) what total amount did each specified NGO receive and (c) what amount of the total specified amount received did each specified NGO spend on (i) administration and (ii) core service delivery?
Reply:
(a) The number of non-governmental organisations (NGOs) subsidised in the 2014/2015 financial year per province:
PROVINCE |
NUMBER OF FUNDED ORGANISATIONS |
TOTAL AMOUNT ALLOCATED TO NGOs |
|
EASTERN CAPE |
2416 |
496, 417 000.00 |
|
FREE STATE |
1613 |
1680 |
347, 637 732.00 |
GAUTENG |
2791 |
1 530 972 449.00 |
|
KWA-ZULU NATAL |
2945 |
783, 218 348.00 |
|
LIMPOPO |
2058 |
442, 000 000. 00 |
|
MPUMALANGA |
1263 |
461 135 000.000 |
|
NORTHERN CAPE |
1029 |
204, 4338 38.00 |
|
NORTH WEST |
812 |
264, 701 727.97 |
|
WESTERN CAPE |
2320 |
2151 |
964, 774 190.00 |
(b) The Provincial Departments of Social Development are currently at different phases of funding the NPOs. The provinces implement a combination of unit costs and programme funding in the financing of services rendered by non-profit organisations (NPOs). Some provinces have been providing a per capita rate for most of the subsidised programmes based on the number of beneficiaries serviced. The subsidy, which is based on the available resources, covers the overall costs of the service including administration, human resources and goods and services.
It is therefore difficult to provide a breakdown in respect of expenditure for (i) administartion and (ii) core service delivery.
27 September 2016 - NW1722
Bilankulu, Ms NK to ask the Minister of Water and Sanitation
(a) What progress has been made with regard to the Bucket Eradication Programme in the provinces where the specified programme has not been fully implemented and (b) what are the reasons for the delay in the completion of the specified programme?
Reply:
(a) The Bucket Eradication Programme is being implemented in the Northern Cape, Free State, North West and Eastern Cape Provinces, and the progress is indicated in the table below:
Province |
Targets |
Units Completed |
Flushing |
Not yet Flushing |
Remaining to be constructed |
Northern Cape |
7618 |
7056 |
3685 |
3371 |
562 |
Eastern Cape |
3319 |
3269 |
2919 |
350 |
50 |
North West |
223 |
223 |
223 |
0 |
0 |
Free State |
13880 |
13698 |
1827 |
11871 |
182 |
|
25040 |
24246 |
8654 |
15592 |
794 |
(b) Below are reasons for the delay in the completion of the specified programme:
- Extreme difficult soil conditions exist in the Northern Cape with moderate conditions in the Free State Province which requires sophisticated machinery to enable the excavation of the rock formations;
- In some towns, the extent of the sewer and water reticulation is in excess of 50km which with some difficult soil conditions slows the excavation process;
- Due to the flat terrain of some projects, deep excavations for services, often as deep as 3m must be excavated to ensure gravity flows once connected;
- Disruptions of existing services (due to excavations without drawings or designs of where existing services are located) such as water and electricity in some projects necessitate stoppages so as to restore the service before commencement.
- The non-availability of materials (toilet structures, pipelines for water and sewer, conservancy tanks) have posed an additional delay in terms of acquiring such from suppliers often outside of the province;
- Community protests or disputes over daily labour rates have delayed the project in some provinces for up to 3 weeks at a time.
---00O00---
27 September 2016 - NW1683
Lorimer, Mr JR to ask the Minister of Mineral Resources
(1) With reference to his reply to question 1418 on 11 August 2016, what (a) were the terms and conditions of the specified mining permit that was not complied with that led to the specified permit’s withdrawal and (b) is the relationship between the communal property association and the original claimants to the specified portion of land; (2) whether all members of the specified communal property association are original land claimants; if not, why not; if so, what are the relevant details; (3) whether any safety inspections have been conducted on the specified operation (a) in (i) 2013, (ii) 2014 and (iii) 2015 and (b) since 1 January 2016; if not, in each case, why not; if so, in each case, what are the relevant details; (4) whether any administrative notices have been issued to Oersonskraal Mining (Pty) Ltd since the granting of the specified mining permit; if not, why not; if so, what are the relevant details; (5) what are the full relevant details regarding the value of benefits transferred by Oersonskraal Mining (Pty) Ltd to the specified communal property association since it commenced operations on the specified portion of land?
Reply:
1. (a)There were no terms and conditions of the permit as the permit was not issued.
(b)The Department of Rural Development and Land Affairs will be in a better position to respond to this question
2. The department Rural Development and Land Affairs will be in a better position to respond to this question
3. Should be referred to Mine Health and Safety
4. A notice in terms of section 93 of the MPRDA was issued on 17 August 2011. Issues to be addressed related to Environmental matters as well as implementation of the Social and Labour Plan.
5. The right holders are not obliged to report to the Department of any payments made to communities.
Approved/not approved
Mr MJ Zwane, MP
Minister of Mineral Resources
Date Submitted:-………………/………………/2016
27 September 2016 - NW1918
Motau, Mr SC to ask the Minister of Transport
Whether, with reference to her replies to questions (a) 415 on 8 March 2016 and (b) 1603 on 7 June 2016, a deadline has been set by which the new Chief Executive Officer of the Passenger Rail Agency of South Africa will be appointed; if not, why not; if so, by what date?
Reply:
The Minister in consultation and by agreement with the Board of PRASA resolved at a meeting held on the 30th June 2016, that the environment within PRASA was not conducive for the appointment of the GCEO. In this regard, and following this agreement with the Board, the Minister seconded and the Board appointed Mr. Collins Letsoalo as Acting Group CEO effective 1 July 2016.
27 September 2016 - NW1892
Maynier, Mr D to ask the Minister of Mineral Resources
(1)Whether, with reference to his media statement of 1 September 2016, the report of the recommendations (a) was tabled at and (b) approved by Cabinet; if not, in each case, why not; if so, in each case, on what date was the specified report (i) tabled at and (ii) approved by Cabinet; (2) whether he was authorised to release the specified media statement; if not, why not; if so, by whom; (3) when was an Inter-Ministerial Committee to investigate the termination of financial services to Oakbay Investments (Pty) Ltd established and (b) by whom; (4) whether he intends to pursue the recommendations of the specified report; if not, why not; if so, what are the relevant details; (5) whether he intends to pursue the recommendation of the establishment of a Judicial Commission of Inquiry into the termination of financial services to the company, since the company has recourse to the courts; if not, why not; if so, why?
Reply:
The Minister of Mineral Resources released a statement on 01 September 2016. This was followed by an interview on SABC news on 02 September 2016. The Minister was not speaking in his personal capacity but in his capacity as Chairperson of the IMC. On 13 April 2016, Cabinet established an IMC to consider allegations that certain banks and other financial institutions acted unilaterally and allegedly in collusion, when they closed bank accounts and/or terminated contractual relationships with Oakbay Investments. The Minister recorded recommendations made to Cabinet by the IMC as well as the related resolutions taken by Cabinet at its meetings of 06 July 2016 and 31 August 2016 respectively. The IMC made 5 recommendations to Cabinet. 4 of the recommendations were approved by Cabinet and 1 was referred to the President for further consideration as it was not within the purview of Cabinet to take a decision on the matter. The Minister is not at liberty to make any further statements on this matter.
Approved/not approved
Mr MJ Zwane, MP
Minister of Mineral Resources
Date Submitted:-………………/………………/2016
27 September 2016 - NW1812
Basson, Mr LJ to ask the Minister of Water and Sanitation
Whether her department had any unspent budget funds at the end of the 2015-16 financial year; if not, what is the position in this regard; if so, (a) what was the amount of unspent budget funds at the end of the specified financial year and (b) what amount of unspent funds, if any, did she request the National Treasury to roll over; (2) Whether the National Treasury approved the roll-over of any unspent funds; if not, why not; if so, what amount?
Reply:
(1) My Department did have unspent budget funds at the end of the 2015-16 financial year.
(1)(a) My Department has recorded an under expenditure of R189.558 million for the 2015-16 financial year.
(1)(b) Of the reported under expenditure of R189.558 million, my Department had requested to rollover funds from 2015-16 financial year to 2016-17 financial year in an amount of R77.448 million.
(2) National Treasury did not grant approval to the Department’s request for rollover of funds as it has been deemed that the Department can accommodate the related expenditure within the existing baselines.
---00O00---
27 September 2016 - NW1810
Lorimer, Mr JR to ask the Minister of Mineral Resources
(1)How many appeals (a)(i) are pending in terms of section 96 of the Minerals and Petroleum Resources Development Act, Act 28 of 2002, as amended and (ii) were pending as at 1 April 2016 and (b) have been dealt with in each of the past five months of the 2016-17 financial year, in each case indicating the number of appeals (i) granted and (ii) denied; (2) (a) for how many days has the oldest pending appeal been outstanding and (b) what plans have been put in place to address the specified pending appeals?
Reply:
1(a) (i) As at 31 August 2016 the number of outstanding appeals are 957.
1(a) (ii) At 1 April 2016, the number of outstanding appeals were 947.
1(b) The following number of appeals were finalised in the months as indicated
April 2016 - 4 Appeals
- Appeals granted – 1
- Appeals dismissed – 3
May 2016 – 6 Appeals
- Appeals Granted – 4
- Appeals Dismissed – 2
June 2016 – 31 Appeals
- Appeals granted – 27
- Appeals dismissed – 4
July 2016 – 20 Appeals
- Appeals granted – 10
- Appeals dismissed – 10
August 2016 – 10 Appeals
- Appeals granted – 4
- Appeals dismissed – 6
2(a) Considering the timeframes provided for in Regulation 74, it takes approximately 120 days to process and finalise internal appeals in the prescirbed manner. The attainment of this period is dependent on number of appeals received during a given period as well as the complexity of such appeals and capacity constrains. The 2010 Constitutional Court judgement in Bengwenyama held that internal remedies must exhuasted before judicial review proceedings may be instituted. This led to the lodgement of significantly more appeals than before as more applcants were required to exercise internal remedies.
2(b) Action Plans:
- There is a continuous liaison with internal and external parties involved to expedite conclusion of the Regulation 74 process which appears to be yielding positive results.
- From time to time, the Office of the State Attorney is requested to assist with the finalisation of certain appeals.
- While implementing the above measures, historic appeals are prioritised.
- Draft regulations to significantly streamline the appeal process has already been formulated and is to be promulgated soon.
Approved/not approved
Mr MJ Zwane, MP
Minister of Mineral Resources
Date Submitted:-………………/………………/2016
27 September 2016 - NW1924
Stander, Ms T to ask the Minister of Transport
Who conducts training at the Road Traffic Management Corporation, (b) when was the tender to provide training issued, (c) to whom was the specified tender awarded, (d) on what basis was the service provider provides the highest standard of training?
Reply:
(a) Training at the Road Traffic Management Corporation is conducted by the RTMC Training Provisioning Unit, a unit within the RTMC Structure.
(b) Not Applicable (See A)
(c) Not Applicable (See A)
(d) Not Applicable (See A)
(e) Not Applicable (See A)
27 September 2016 - NW1773
America, Mr D to ask the Minister of Transport
(1)Whether there are any delays in the delivery of the trains that were manufactured in Brazil under the Gibela Manufacturing and Supply Agreement; if so, what (a) were the originally agreed upon dates for the delivery of the specified trains under the specified agreement, (b) were the actual dates of delivery, (c) are the reasons for the delays in each case and (d) are the financial implications, in each case; 2) what (a) is the price of each train that still needs to be delivered under the specified agreement and (b) are the estimated differences between the agreed upon and actual costs of the specified trains?
Reply:
1. There have been no delays in the delivery of the trains manufactured in Brazil. Of the total 20 trains from Brazil, 10 trains have been delivered to the Wolmerton Depot Testing Facility as per the Schedule.
The table below provides the response for (a) and (b), i.e., the delivery dates of the new trains to Wolmerton Depot from Brazil:
Train No. from Brazil |
Target delivery date |
Actual Delivery Date to Wolmerton Depot |
1 |
December 2015 |
20 December 2015 |
2 |
February 2016 |
26 February 2016 |
3 |
April 2016 |
01 April 2016 |
4 |
April 2016 |
18 April 2016 |
5 |
May 2016 |
19 May 2016 |
6 |
June 2016 |
08 June 2016 |
7 |
July 2016 |
04 July 2016 |
8 |
July 2016 |
13 July 2016 |
9 |
July 2016 |
27 July 2016 |
10 |
August 2016 |
19 August 2016 |
(c) N/A
(d) N/A
2. (a) The total value of the contract is R59 billion (excluding inflation) for 600 new trains
(b) There is no difference between the agreed upon price and the actual costs of the new trains.
27 September 2016 - NW1754
Mulder, Dr PW to ask the Minister of State Security
Whether his department has met the requirements of the Use of Official Languages Act, Act No 12 of 2012, according to which his department (a) has established an official language policy for the department and (b) instituted a language unit; if not, (i) why not and (ii) what steps he will take to ensure that the provisions of the Act are met; if so, what are the relevant particulars?
Reply:
(a) The State Security Agency (SSA) is in the process of establishing an official language policy for the department.
(b) (i) The establishment of a language unit will be addressed on the approval of the official language.
(ii) The department is currently in the process of determining the relevant languages per province that should be included in the official language policy
27 September 2016 - NW1827
Hoosen, Mr MH to ask the Minister of Transport
(a) What are the (i) time frames and (ii) milestones for the implementation of periodic testing of vehicles, (b) at what stage is her department in this regard, (c) what delays, if any, have taken place and (d) what steps were taken by her department to resolve the specified delays?
Reply:
(a) (i) No time frames have been developed yet.
(ii) Department is currently busy with development of a process to deal with fraud and corruption within the motor vehicles testing environment to ensure that issuance of fraudulent road worthy certificates is reduced and ultimately eradicated.
(b) The Department is currently engaging with the sector on the development of a system that may be used by the testing station when testing motor vehicles to ensure that vehicles presented for the test instead of only the documentation being submitted. It is common knowledge that, if one was used to buying a fraudulent road worthy certificate they can still continue buying it, therefore it is critical that the environment be cleaned before you introduce a requirement that will only generate money but not assisting us in dealing with unroadworthy motor vehicles.
(c) The consultation on the finalisation of the appropriate system that can be incorporated in the vehicles testing environment and the cost implications.
(d) Consultations are still ongoing and no further delays are anticipated. It must further be noted that Periodic Vehicle Testing alone will not alone have an impact on reduction of fatalities hence the support by traffic law enforcement is prioritised.
27 September 2016 - NW1769
Hunsinger, Dr CH to ask the Minister of Transport
Has the SA Maritime Safety Authority applied the preference points and prescribed formula system in the awarding of all contracts within supply chain and procurement as expressed in (a) paragraph 2 of the Preferential Procurement Policy Framework Act, Act 5 of 2000, and (b) section 51 of the Public Finance Management Act, Act 1 of 1999, as amended; if not, why not; if so, (i) which contracts and (ii) to what value?
Reply:
(a) Yes, the preferential point system (in line with PPPFA) was applied on all transaction above R30,000.00
(b) Yes, a competitive bidding was followed for all transaction above R500,000.00
(i) And (ii) below is the list of all contracts awarded, preferential point system or method use and the transaction values for each contract.
No |
Name of Supplier |
Description (Contracts) |
Evaluation Method |
Value |
1 |
Dinco Trading CC |
Stationery |
80/20 |
R137,894.83 |
2 |
Diventia Investments (PTY) LTD |
Stationery |
80/20 |
R123,700.00 |
3 |
Internet Solutions |
MPLS |
90/10 |
R359,901.98 |
4 |
MAKAVASA TRADING |
Laminating Pouches |
80/20 |
R63,000.00 |
5 |
Moribo wa africa trading enterprise |
S-Clip files |
80/20 |
R102,600.00 |
6 |
Nyalu Communications |
Marketing Collateral |
80/20 |
R39,680.08 |
7 |
PC Palace Gauteng |
Computer Equipment: Dell Optiplex |
80/20 |
R58,605.12 |
8 |
RAMBALANE TRADING PROJECTS |
Stationery |
80/20 |
R115,000.00 |
9 |
RAPOO RESOURCES(PTY) LTD |
Stationery |
80/20 |
R60,950.00 |
10 |
Ritlaku Trading Enterprise and Projects (Pty) LTD |
Stationery |
80/20 |
R35,600.00 |
11 |
Dimbuli Trading |
Stationery |
80/20 |
R90,000.00 |
12 |
DNV Business Assurance South Africa |
Insurance |
80/20 |
R280,203.45 |
13 |
RAPOO RESOURCES(PTY) LTD |
Stationery |
80/20 |
R150,000.00 |
14 |
WingsNaledi Corporate Travel Pty Ltd |
Travel & Accommodation |
90/10 |
R1,384,985.47 |
15 |
A New Aworkening Trading |
First Aid Room Equipment |
80/20 |
R344,251.84 |
16 |
LPV De Swardt |
Job Evaluation & Grading |
80/20 |
R39,250.00 |
17 |
TEKWENI TV PRODUCTION cc |
Ship Repair Safety DVD |
80/20 |
R62,700.00 |
18 |
Internet Solutions |
MPLS |
80/20 |
R364,161.91 |
19 |
KNMC Consultants |
UPS installation - Richardsbay |
80/20 |
R179,208.00 |
20 |
WingsNaledi Corporate Travel Pty Ltd |
Travel & Accommodation |
90/10 |
R1,520,859.55 |
21 |
Azas Projects (Pty) Ltd |
UPS installation – Port Elizabeth |
80/20 |
R204,495.00 |
22 |
KNMC Consultants |
UPS installation - Durban |
80/20 |
R443,916.00 |
23 |
MATHAMANE TRADING ENTERPRISE |
Furniture |
80/20 |
R55,500.00 |
24 |
Bathlodi Trading and Projects |
Catering: Careers Expo |
80/20 |
R46,500.00 |
25 |
Precision Networks |
Laptops |
80/20 |
R72,331.40 |
26 |
Internet Solutions |
MPLS |
90/10 |
R347,251.13 |
27 |
Internet Solutions |
MPLS |
90/10 |
R317,549.49 |
28 |
WingsNaledi Corporate Travel Pty Ltd |
Travel & Accommodation |
90/10 |
R1,156,839.79 |
29 |
WingsNaledi Corporate Travel Pty Ltd |
Travel & Accommodation |
90/10 |
R1,050,296.51 |
30 |
RAPOO RESOURCES(PTY) LTD |
Stationery |
80/20 |
R50,400.00 |
31 |
Sage Computer Technologies |
Wireless Link for Hillcrest Office |
80/20 |
R217,321.12 |
32 |
Fujitsu Service Core (Pty) Ltd |
Server Maintanance |
80/20 |
R73,596.51 |
33 |
Internet Solutions |
MPLS |
90/10 |
R351,849.91 |
34 |
WingsNaledi Corporate Travel Pty Ltd |
Travel & Accommodation |
90/10 |
R1,223,863.91 |
35 |
Biztech (PTY) Ltd |
National Boat Show |
80/20 |
R48,974.40 |
36 |
Business Connexion (Pty) Ltd |
Software: Varonis Renewal |
80/20 |
R131,345.43 |
37 |
Mccarthy |
Vehicle |
80/20 |
R315,000.00 |
38 |
Precision Networks |
Laptops |
80/20 |
R31,689.72 |
39 |
Introstat (Pty) Ltd |
Laptops |
80/20 |
R42,952.22 |
40 |
Internet Solutions |
MPLS |
80/20 |
R351,849.91 |
41 |
Itgility (Pty) Ltd |
Dell NX400 storage |
80/20 |
R80,469.34 |
42 |
3G Relocations and transport |
Transversal Contract |
R35,205.25 |
|
43 |
Basadzi Personnel cc |
Advert |
80/20 |
R106,557.90 |
44 |
OUTSOURCING DIGITAL |
UPS Installation: Pretoria |
80/20 |
R139,953.24 |
45 |
PC Palace Gauteng |
Software: CITRIX Licence |
80/20 |
R149,796.00 |
46 |
Sizwentsuluba VSP |
Internal Audit |
90/10 |
R281,748.00 |