Questions and Replies
04 October 2023 - NW2922
George, Dr DT to ask the Minister of Finance
(1)Whether, with regard to the cost-of-living crisis that is currently exhibited most notably by the upward spiralling high food prices that are squeezing the average South African household, he intends to reconsider the position he outlined during questions for oral reply on 21 September 2022 in respect of the proposal by a certain political party (details furnished) to expand the zero-VAT rated basket of food items as a direct intervention; if not, why not; if so, what are the relevant details; (2) with regard to the announcement made by the Minister in The Presidency, Ms K P S Ntshavheni, that the Economic Cluster has been instructed by the President to develop a food security plan of action, what action is being taken by the National Treasury to relieve food insecurity of households in the Republic?
Reply:
- The position of the Minster has not changed since the last oral reply. As indicated then, zero-rating of specific foodstuffs provides a larger proportional benefit to the poor (i.e. progressivity is enhanced). Overall, goods have a progressive impact and a strong equity-gain ratio – poor people consume a relatively high share of zero-rated items. Nevertheless, the analysis of the independent panel in 2018 indicated that extending zero-rating to further food items would be inefficient, since high-income households tend to benefit more from such measures.
- We acknowledge the importance of the agricultural sector in tackling the issue of food insecurity which can both be addressed by increasing availability of food and affordability of food. National Treasury provides fiscal support to departments to support the agricultural sector. The fiscal support for agricultural sector is determined through the budget allocations to the Department of Agriculture, Land Reform and Rural Development, as articulated in the Estimate of National Expenditure (ENE) -Vote 29 and to provinces though the Division Revenue Act, and this information is available in various provincial budgets.
- Consolidated spending allocations for agriculture and rural development, as presented in the 2023 Budget, are R27.8 billion in 2023/24, R28.6 billion in 2024/25 and R29.9 billion in 2025/26.
04 October 2023 - NW2869
Manyi, Mr M to ask the Minister of Finance
What are the full details of the (a) total amount of the public debt of the Republic and (b) debt of (i) state-owned companies and (ii) municipalities that have been underwritten by the national fiscus as a percentage of Gross Domestic Product?
Reply:
(a) Gross debt of the national government is disclosed in Table 7.7 of the 2023 Budget Review. It is estimated to reach R5.06 trillion or 72.2 per cent of GDP by the end of the 2023/24 Financial Year.
(b) (i) Government guarantee exposure to state-owned companies is disclosed on Table 7.10 on page 91 of the 2023 Budget Review, and these are explicitly underwritten. Other contingent liabilities are included with the provisions in Table 7.11 on page 92 of the 2023 Budget Review.
(ii) There is no debt (borrowing) or loans taken up by municipalities that have been underwritten by the national fiscus. Chapter 6 of the MFMA sets the legal framework that enables municipalities to take their own decisions regarding borrowing. Specifically, sections 50 and 51 of the MFMA deal with municipal guarantees and national and provincial guarantees.
This decision-making process for Municipal Councils were empowered by the Amendment to the Constitution of the Republic, in section 230A. Therefore, Municipalities borrow on the strength of their own financial standing and status.
04 October 2023 - NW2838
Cuthbert, Mr MJ to ask the Minister of Higher Education, Science and Innovation
What (a) number of students who are funded by the National Student Financial Aid Scheme fall into the (i) R0 - 180 000, (ii) R180 001 - R350 000 and (iii) R350 001 - R600 0000 income bands and (b) proportion of funds are cumulatively allocated to each of the specified bands?
Reply:
NSFAS currently does not categorize as specified above. Financial assessment is based on household income (threshold) of R350 000 for non-disability and 600 000 for disability applicants.
04 October 2023 - NW2918
Manyi, Mr M to ask the Minister of Finance
Whether the Government has run out of money; if not, what is the position in this regard; if so, what are the relevant details?
Reply:
Government is working to manage public finances in a prudent and sustainable manner. This includes appropriately responding to the materialization of risks, include unforeseen economic and financial conditions. To be clear, the Government has not run out of money. Government publishes the "Statement of the National Government’s Revenue, Expenditure, and Borrowing" monthly, available on the National Treasury website. This statement provides detailed information into government revenue collections, expenditure and borrowing.
Revenue collections for the first four months of 2023/24 have performed below expectations, primarily due to under-collections in corporate income tax and higher VAT refunds. Therefore, the main budget deficit for the first four months of 2023/24 is higher than expected.
Compared to the 2023 Budget, the economic and revenue outlook has deteriorated, and tighter financial conditions have constrained government’s borrowing programme and led to higher borrowing costs. Government remains committed to prudent fiscal management and addressing these challenges to ensure the financial stability of the nation.
04 October 2023 - NW2710
Faber, Mr WF to ask the Minister of Finance
(1)(a) What is the position of the National Treasury on the BRICS nations’ proposal to introduce a new currency for cross-border trade and (b) how will this proposal impact the Republic’s economic relations with other countries, particularly the United States (US); (2) given the potential impact of a new BRICS currency on the economic relations of the Republic with the US, what steps will the Government take to ensure that its participation in this initiative does not negatively affect its existing trade relationships with the US and the European Union countries?
Reply:
- (a) & (b)
There is no official proposal to introduce a new BRICS currency at this point.
The current discussion on facilitating trade and finance amongst the BRICS members is captured in the Johannesburg Declaration where BRICS Leaders highlighted the following:
“We stress the importance of encouraging the use of local currencies in international trade and financial transactions between BRICS as well as their trading partners. We also encourage strengthening of correspondent banking networks between the BRICS countries and enabling settlements in the local currencies. We task our Finance Ministers and/or Central Bank Governors, as appropriate, to consider the issue of local currencies, payment instruments and platforms and report back to us by the next Summit”.
In the BRICS Finance Track, Finance Ministers and Central Bank Governors will resume discussions regarding the instruction from the leaders to explore payment instruments and infrastructure of using local currencies for enhance trade.
2. As stated before, BRICS countries are not establishing a BRICS common currency.
To date, the United States and the European Union remain one of the largest trading partners of South Africa. South Africa trade relations with the United States and the European Union are governed by existing trade agreements with these trading partners. Any changes in the trade agreements are negotiated and agreed between the two countries.
04 October 2023 - NW2772
Herron, Mr BN to ask the Minister of Public Enterprises
(1) With reference to the reply of the Minister of Mineral Resources and Energy, Mr S G Mantashe, to question 2266 on 30 June 2023, that the grid capacity constraints has no linkage with Karpowership and in view of Eskom’s Generation Connection Capacity Assessment of the 2024 Transmission Network that a total of 1220MW is being reserved for Karpowership (details furnished), furthermore considering that there is an urgent need to end load shedding and noting that although during Bid Window 6 of the Renewable Independent Power Producer Programme, only 1000MW out of 4200MW was procured and the rest were rejected in the Eastern and Western Cape, due to insufficient grid space, the grid space remains reserved since 2021 for Karpowership in the Eastern Cape, Western Cape and Richards Bay, and given that Karpowership’s environmental authorisations remain refused and the current court cases on its generation licences could take many years to resolve, (a) what is the justification for the prioritisation of the Karpowership deal over adding new capacity through wind and solar energy and (b) by what date will the portion of the grid reserved for the Karpowership be released; (2) whether, given that Karpowership is holding up the grid space and the urgency to end the loadshedding, there will be a limit to the extension that is being given to Karpowership to reach the commercial and financial deadline; if not, what is the position in this regard; if so, what is the (a) current and (b) final commercial and financial close deadline for Karpowership; (3) given the grid constraints, what laws, policy and/or factors does Eskom rely on in its decision to (a) reserve the grid for independent power producers (IPPs) before commercial and financial close deadline and (b) release the grid that is reserved for a particular IPP?
Reply:
According to the information received from Eskom
1. (a)
The Karpowership projects are three of 11 preferred bidders selected under the Risk Mitigation IPP Programme (RMIPPP), which have applied for and been provided Budget Quotations in line with the procurement process and the associated grid application process. There is therefore no prioritisation of these projects over others.
1 (b)
Please see answer 2 below.
2. (a) and (b)
It is acknowledged that the Risk Mitigation IPP Programme has faced delays due to the changes in global economic conditions which have impacted these projects’ ability to reach commercial close. As a result, the Department of Mineral Resources and Energy (DMRE) as procurer, has communicated a long stop date for the RMIPPP of 31 December 2023, by which time the projects under this programme will have to achieve legal close. Accordingly, the Budget Quotations issued to all the remaining preferred bidders under the Risk Mitigation IPP Programme have been extended to 31 December 2023, to enable these projects to achieve legal close.
3 (a)
It is to be noted that Eskom has not concluded on the issue of reservation of capacity, thus there is no policy that defines reservation of capacity. However, in terms of section 22(2) of the Electricity Regulatory Authority (ERA), the licence holder is permitted, with the concurrence of NERSA, to discriminate for objectively justifiable and identifiable reasons. The purpose of the reservation of capacity, to the extent that it is approved by the relevant stakeholders including the Regulator, will be to secure an orderly allocation of access to the grid.
The context is that currently there is saturation of the grid by private parties. Often, private parties request access to the grid without shovel-ready projects and this prejudices those projects that can demonstrate readiness, including the government section 34 programme, which ought to go through, among others, regulatory and other approvals (e.g., PFMA), whereas private parties are not subjected to these onerous processes.
The formal IPP programmes are initiated following the section 34 determinations issued by the Minister of Mineral Resources and Energy in terms of the Electricity Regulation Act and concurred to by NERSA, which are administrative actions. The preferred bidders to these programmes therefore apply for and are provided with Budget Quotations. Any extensions to the Budget Quotation validity for the section 34 IPP preferred bidder projects are taken in line with a request from the preferred bidder and having due consideration of the time required for the attainment of certain approvals (required by either the Procurer or the Buyer) and the associated legal and financial commercial close dates as communicated by the Department of Mineral Resources and Energy.
3 (b)
Please see the response under Question 2.
Remarks: Approved / Not Approved
Jacky Molisane PJ Gordhan, MP
Acting Director-General Minister
Date: Date:
04 October 2023 - NW2909
Buthelezi, Mr EM to ask the Minister of Finance
How does the National Treasury ensure that municipalities comply and lock their adjusted budgets and/or financial systems at the end of each month to ensure prudent financial management?
Reply:
The Municipal Regulations on a Standard Chart of Accounts (mSCOA), Gazette No. 37577, 2014, was promulgated on 22 April 2014. All municipalities and municipal entities had to comply with the mSCOA Regulations by 01 July 2017. In terms of mSCOA, municipalities should budget, transact and report on all six (6) legislated mSCOA segments and submit the required data strings as per the legislated timeframes to the National Treasury’s Local Government Database and Reporting System (LGDRS). The budget and adjustments budgets adopted by Council must be locked on the core municipal financial system before submitting the data strings to the LGDRS. Most of the municipal financial systems have built-in controls that do not allow transacting if the budget or adjustments budget has not been locked. Also, Section 65(2)(j) of the MFMA requires that the accounting officer must take all reasonable steps to ensure that all financial accounts of the municipality are closed at month-end and reconciled with its records before submitting the monthly data string to the LGDRS.
As communicated in MFMA Budget Circular No. 123 dated 03 March 2023, the LGDRS is locked on the 10th working day of the month following the legislated deadline. The late submissions of data strings are not accepted by the LGDRS. The timeous submission of credible mSCOA data strings to the LGDRS has been included in the equitable share release criteria for 2023/24 that was communicated in MFMA Circular No. 122 (dated 09 December 2022).
Since the financial system must be locked at the end of the month to generate mSCOA data strings, municipalities may not open during closed periods to correct errors. Errors must be corrected in the next open period. Providers of municipal financial systems have also been instructed by the National Treasury in 2019 to ensure that the necessary internal controls are built into the financial system to prevent the opening during closed periods on the financial system and the bypassing of such controls.
04 October 2023 - NW2742
Chetty, Mr M to ask the Minister of Finance
(a) What total amount did (i) the National Treasury and (ii) each entity reporting to him pay for printed copies of the integrated annual reports in the (aa) 2020-21, (bb) 2021-22 and (cc) 2022-23 financial years, (b) who were the suppliers in each case and (c) what total number of copies of the report were printed (i) in each case and (ii) in each specified financial year?
Reply:
(i) NATIONAL TREASURY
Financial years |
(a) Total amount |
(b) Name of supplier |
(c) Total number of copies printed |
(aa) (i)(ii) 2020-21 |
The Annual Report was not printed. |
||
(bb) (i)(ii) 2021-22 |
R87 845,28 |
Lebone Litho Printers |
120 |
(cc) (i)(ii) 2022-23 |
Not in printing process yet. |
(ii) ENTITIES
1. Accounting Standards Board (ASB)
From the Accounting Standards Board
We do not print our Annual Report/Integrated Report/Annual Financial Statements. All our reports are made available electronically.
2. Co-operative Banks Development Agency (CBDA)
Reference |
Financial Year |
Amount Paid |
Copies |
Supplier |
2742(a)(aa) |
2020-21 |
Nil |
Nil |
Not Applicable |
2742(a)(bb) |
2021-22 |
Nil |
Nil |
Not Applicable |
2742(a)(cc) |
2022-23 |
Nil |
Nil |
Not Applicable |
3. Development Bank of Southern Africa (DBSA)
4. Financial Intelligence Centre (FIC)
(a) (ii) (aa) 2020-21 – R0
(bb) 2021-22 – R0
(cc) 2022-23 – R0
(b) Not applicable
(c) (i) and (ii) Not applicable. The Financial Intelligence Centre did not produce printed copies of its annual reports in the 2020-21, 2021-22 and 2022-23 financial years.
5. Financial Sector Conduct Authority (FSCA)
(a) The total amount (ii) Financial Sector Conduct Authority (FSCA) printed copies of the annual reports in;
(aa) 2020 – 2021: 150 total copies
RP292/2021
ISBN: 978-0-621-49765-6
Title of Publication: Annual Report 2020/2021 Financial Sector Conduct Authority (FSCA)
Printing costs: R44 676.35
Supplier: Shereno Printers
(bb) 2021 –2022: 150 total copies
RP282/2022
ISBN: 978-0-621-50641-9
Title of Publication: Annual Report 2021/2022 Financial Sector Conduct Authority (FSCA)
Printing costs: R47 356.93
Supplier: Shereno Printers
(cc) 2022 – 2023: 150 total copies
RP249/2023
ISBN: 978-0-621-51379-0
Title of Publication: Integrated Report 2022/2023 Financial Sector Conduct Authority (FSCA)
Amount spent: R34 859.59
Supplier: Blackmoon
NB: The 2022/2023 report has not been printed. The figures provided are based on the quotation received from the service provider.
5. Government Employees Pension Fund (GEPF)
7. Government Pensions Administration Agency (GPAA)
(i) Not Applicable to the GPAA
(ii) The table below sets out the amount the GPAA paid for printed copies of the integrated annual reports, the utilised service provider and printed the number of copies in the respective years:
Financial Year |
Service Provide |
Number of Copies |
Amount |
(aa) 2020-21 |
Ulutsha Communication |
200 |
R30 000.00 |
(bb) 2021-22 |
Ulutsha Communication |
500 |
R77 250.00 |
(cc) 2022-23 |
No expenditure incurred to date |
8. Government Technical Advisory Centre (GTAC)
(aa) R17908.95, 40 copies printed.
(bb) R10519.05, 25 copies printed.
(cc) R0, no copies printed.
(b) Grounded Media supplied printed copies in each case.
(c) 65 copies were printed in total.
(i) 40 copies printed in (ii) 2020-21 and 25 copies in 2021-22. No copies have been printed in 2022-23.
9. Independent Regulatory Board for Auditors (IRBA)
10. Land and Agricultural Development Bank of South Africa (Land Bank)
- Land Bank has not printed Integrated Annual Reports for FY2020-21, FY2021-22, and FY2022-23. The Bank has only produced electronic versions of the Integrated Annual Reports for the specified period.
- Land Bank did not procure any suppliers for the printing of the Integrated Annual Reports.
- No Integrated Annual Reports were printed by the Bank.
11. Office of the Ombud for Financial Services Providers (FAIS Ombud)
Integrated Reports:
The FAIS Ombud has incurred no expenditure with respect to Integrated Annual Reports for the financial periods 2020-21 to 2022-23.
Annual Reports:
Annual expenditure incurred by the Office on the publication of annual reports for the financial periods 2020-21 to 2022-23 is as follows:
NO |
Financial Period |
Service Provider |
No. of Copies |
Amount |
1. |
2020-21 |
Lebone Litho Printers |
150 |
R54,353.45 |
2. |
2021-22 |
Litha Communications |
150 |
R96,340.68 |
3. |
2022-23 |
Lezmin 2771 CC |
50 |
*R83,317.60 |
* Amount as per signed purchase order. As at 4 September 2023, the payment for the 2022-23 annual report has not been processed.
12. Office of the Pension Funds Adjudicator (OPFA)
Question |
2020-21(aa) |
2021-22(bb) |
2022-23(cc) |
(a) |
R112 299.62 |
R99 690.05 |
R122 245.00 |
(b) |
Broadsword Communication |
Broadsword Communications |
Seriti Printing Digital |
(c) |
100 printed copies (Including design and editing) |
100 printed copies (Including design and editing) |
100 printed copies (Including design and editing) |
13. Office of the Tax Ombud (OTO)
14. Public Investment Corporation SOC Ltd (PIC)
(a)(ii)
(aa) 2020/21 Book one: Integrated Annual Report at a cost of R84 500 (excluding VAT); and Book two: Annual Financial Statements at a cost of R55 643.50 (excluding VAT).
(bb) 2021/22 Book one: Integrated Annual Report at a cost of R93 705 (excluding VAT); and Book two: Annual Financial Statements at a cost of R65 015 (excluding VAT).
(cc) 2022/23 Book one: Integrated Annual Report at a cost of R131 400 (excluding VAT); and Book two: Annual Financial Statements at a cost of R58 200 (excluding VAT).
(b)
(b) Msomi Africa Communications was the supplier for all three of the above-mentioned financial years.
(c)
(i) and (ii)
2020/21 700 copies printed
2021/22 500 copies printed
2022/23 800 copies printed
15. Sasria SOC Ltd
2020-2021: R29,500-00 (Exl VAT); Msomi Africa Communication (PTY) Ltd; 100 printed copies [R295-00/copy]
2021-2022: Quoted R11,800-00 (Exl VAT); Msomi Africa Communication (PTY) Ltd; 30 printed copies [R393-33/copy]
2022-2023: Not yet finalized
16. South African Revenue Service (SARS)
a) (ii) (aa) (bb) (cc) SARS did not print annual reports for the 2020 – 2021 financial years. The annual report was only printed for the 2022-23 financial year at the total amount of R140 000.
b) The supplier who was appointed for SARS annual report printing is Shereno Printers.
c) (i) (ii) The total number of copies that were printed was 250 for the 2022-23 financial year.
04 October 2023 - NW2767
Hendricks, Mr MGE to ask the Minister of Finance
Whether he will introduce a general tax anti-avoidance policy that gives authority to the SA Revenue Service and other bodies to monitor acts pertaining to illicit financial flows; if not, why not; if so, what are the relevant details?
Reply:
Illicit financial flows (IFFs) take a variety of forms and are addressed by several bodies, including SARS. SARS takes action with respect to IFFs that have a tax or customs aspect in terms of the Income Tax Act, 1962, Customs and Excise Act, 1964, and other legislation it administers.
A General Anti-Avoidance Rule (GAAR) is included in the Income Tax Act, 1962, as Part IIA of Chapter III of the Act. The GAAR permits SARS to counter impermissible tax avoidance arrangements that would not be addressed by the other provisions of the Act. While impermissible tax avoidance arrangements may involve IFFs, they may also be restricted to purely domestic arrangements or involve cross-border flows that would otherwise be considered legitimate. Another GAAR is provided for in section 73 of the Value-Added Tax Act, 1991, which deals with schemes for obtaining undue tax benefits in that context. SARS may also make use of common law doctrines, such as “substance over form”, in challenging abusive arrangements.
In addition, a reportable arrangements system is included in the Tax Administration Act, 2011, as Part B of Chapter 4 of the Act. The reportable arrangements system provides for the reporting of arrangements that present a heightened risk of undue tax benefits by their participants or promotors to SARS.
Supplementing the GAAR, South Africa also has tax legislation dealing with more specific avoidance concerns. These include interest limitation rules (recently amended), thin capitalisation rules, controlled foreign company (CFC) rules, as well as transfer pricing rules.
Where SARS identifies IFFs with a tax or customs impact, either through its own efforts or in cooperation with other government entities, SARS applies the legislation and legal tools at its disposal to address the IFFs.
Addressing IFFs remains a consistent and key focus for SARS, the South African Reserve Bank, the Financial Sector Conduct Authority, the Financial Intelligence Centre, the National Prosecuting Authority, the Special Investigating Unit, the Hawks, South African Police Service, and the National Treasury. In this regard, South Africa is actively involved in international efforts aimed at mitigating the problem. Key steps taken in recent times include:
- Becoming a member of the Global Forum of transparency and exchange of information for tax purposes in 2009
- Signing the Multilateral Convention in 2011
- Introducing a Voluntary Disclosure Programme (VDP) in 2012
- Signature of the FATCA Intergovernmental Agreement in 2014
- Introduction of the temporary Special VDP in 2016
- First tax information exchange under the Common Reporting Standard (CRS) in 2017
- Agreeing to the proposal for a minimum global tax rate (Pillar 2) to minimise global financial flows to tax havens (2021)
04 October 2023 - NW2732
Cachalia, Mr G K to ask the Minister of Public Enterprises
With reference to the electricity supply cut off by Eskom to the Ditsobotla Local Municipality, including the town of Lichtenburg, for non-payment (details furnished), what is his position regarding condemning the alleged unconstitutional practices by Eskom and assure the public from their unethical business practices?
Reply:
According to the information received from Eskom
1. On 27 July 2023, Ditsobotla Local Municipality (the Municipality) and other Eskom customers were affected by a loss of supply due to a pylon that fell onto the 88kV powerline between Watershed Transmission substation to the Lichtenburg Distribution substation.
2. As the fallen structure was being repaired, Eskom observed oil leakages on Transformer 2 at Lichtenburg substation. Upon investigation it was discovered that the transformer was damaged in order to steal copper. As a result, the transformer required replacement.
3. Supply was restored to the substation and surrounding areas via Transformer 1. However, during this period only 10 MVA out of the 17 MVA that is required for peak capacity was available to the municipality to supply its customers.
4. A new replacement transformer was identified in Gauteng, with an estimated cost of R6.9 million inclusive of the transport, installation and commissioning.
5. Transformer 2 was installed but not energised, as the Municipality had not paid its current account in full since April 2022. By way of background, a court order in 2017 ruled for eight (8) applicants who are customers of the Municipality, to pay their electricity bills directly to Eskom. These eight consumers are embedded in the Municipality’s electricity network and Eskom relies on the Municipality, as the co-respondent in terms of the court order, for the availability of supply and billing for electricity.
6. Eskom therefore requested that the Municipality pays for the cost of replacing the transformer, their current account, and three months' accounts in advance before the transformer would be energised.
7. Whilst negotiations regarding payment arrangements were underway, it was discovered that Transformer 1 at Lichtenberg substation was experiencing oil leaks.
8. A decision was taken by Eskom to switch on Transformer 2 and remove Transformer 1 for repairs.
9. Engagements with various stakeholders were held and following the repair and commissioning of Transformer 1, the supply to the Municipality was restored.
10. Eskom confirmed that discussions are continuing with the Municipality, the North-West Province, organised business and other stakeholders to find a sustainable solution for electricity supply to the businesses and residents of the Municipality.
11. There is no evidence of “alleged unconstitutional practices” nor “unethical business practices”.
Remarks: Approved / Not Approved
Jacky Molisane PJ Gordhan, MP
Acting Director-General Minister
Date: Date:
04 October 2023 - NW2677
Kruger, Mr HC to ask the Minister of Finance
(1)Given the Auditor-General’s findings of 2020/2021 that 84% of municipalities consistently fall short of the statutory 30-day payment term which imposes a significant financial strain on small companies, sole proprietors and cooperatives, what (a) proactive measures are being developed by the National Treasury to ensure that municipalities honour their financial commitments to these entities within the required time frame and (b) considerations, frameworks and/or potential regulatory interventions are currently being contemplated; (2) what (a) are the details of the account of the fiscal liabilities and (b) proposed financial regulations and/or interventions are intended to enforce adherence to the payment time frame?
Reply:
(1)(a) Creditors with outstanding invoices have been encouraged to escalate matters to the National Treasury through the helpdesk facilities, [email protected], and [email protected], respectively. These are followed up with the respective Municipal Manager and Chief Financial Officer. Copies are also forwarded to the relevant provincial treasuries for their additional oversight, monitoring and facilitation of engagements with the relevant municipality, where required.
(1) (b) Section 65(2)(e) of the Local Government: Municipal Finance Management Act, 2003 (MFMA), requires the Accounting Officer to take all reasonable steps to ensure that all money owing by the municipality be paid within 30 days of receiving the relevant invoice or statement. The National Treasury has issued MFMA Circular 49 which includes a step-by-step approach to be adopted by municipalities to ensure that they consistently fulfil their financial obligations. Additionally, National Treasury has issued standard operating procedures for municipalities in relation to expenditure and liabilities management. These matters are also addressed when requested to develop Financial Recovery Plans.
(2) (a) The National Treasury publishes regular reports as required by section 71 of the MFMA. The latest publication of the Local Government Revenue and Expenditure: Fourth Quarter Local Government Section 71 Report, for the period 1 July 2022 to 30 June 2023, reflects amounts owed by municipalities to creditors for more than 30 days of R75,9 billion for the 4th Quarter of the financial year. The details of which, are available on the National Treasury website.
(2)(b) Accountability arrangements in the MFMA requires the Municipal Council and the Municipal Manager to take disciplinary action against officials responsible for non-compliance with internal control measures.
04 October 2023 - NW2850
Buthelezi, Mr EM to ask the Minister of Finance
What are the details of the budgetary initiatives that the National Treasury has put in place in the past three financial years, which are directly aimed at stimulating the economy of the Republic to ensure that it does not remain a welfare state?
Reply:
One of the key components of the budget is the economic development function, through which funds are allocated to promote sustained and inclusive economic growth, and to address unemployment, poverty and inequality. The various areas of spending include economic infrastructure, industrialisation and exports, innovation, science and technology, agriculture and rural development and job creation. Details of the expenditure are included in the budget documents of the past three years.
The economic recovery plan announced in October 2020 links infrastructure investment and related institutional reforms to support higher economic growth. Government has made progress in implementing the economic recovery plan including in the electricity and transport sectors, roll out of critical infrastructure in water and sanitation, energy and transport as well as the presidential employment initiative.
Public-sector infrastructure expenditure increased from R187.4 billion in 2019/20 to R212.3 billion in 2021/22, and an estimated R255.2 billion in 2022/23. These funds were mainly used to expand power generation capacity, upgrade and expand the transport network, improve sanitation and water services and for social services infrastructure.
Since the inception of the budget facility for infrastructure, a total of R56.8 billion has been approved and allocated to the relevant infrastructure projects, including Limpopo Central Hospital, Gauteng Schools Programme, SA Connect, and Rural Bridges Programme. Since inception, the Infrastructure Fund has helped to package and approve 13 blended finance projects and programmes to the value of R48.8 billion.
Government is working on several reforms to strengthen public investment management and the associated value chain. Many of these involve pooling resources with the private sector in blended finance initiatives aimed at funding and implementing infrastructure projects more effectively.
04 October 2023 - NW2105
Malinga, Ms VT to ask the Minister of Public Enterprises
Noting that Transnet plans to shift the operations of the container corridor between Johannesburg and Durban, which plays a major role in industrialisation, economic growth and social development from state-ownership to private-ownership for the next 20 years, (a) how will the 670 km long electrified rail in the specified container corridor incentivise private investment, given that the Republic is experiencing energy insecurity which may adversely affect the turnaround of operations and (b) does Transnet have regulatory capability to ensure that private-ownership does not make things worse by replacing inefficient and restrained state monopoly, with inefficient and unrestrained private monopoly?
Reply:
According to the information received from TRANSNET
Background:
Transnet prefers retaining the container corridor and to sell slots to third party operators whilst operating some slots but in the absence of immediate financial support for the maintenance of the infrastructure, both the current and the backlog, entering into a 20-year operating lease with a private company is the best option available to keep this important corridor open. Transnet approached the market for a partner to enter into an operating lease for 20 years in order to invest in and grow freight on the corridor that is the backbone of the country’s manufacturing sector. Careful consideration was given to the profile of the potential private partner for the planned Container Corridor Operating Lease. The ideal partner must have an established presence in the supply chain; the ability to leverage Transnet and other rail terminals in rail-based logistics solutions; have access to inexpensive capital and the ability to introduce more efficient procurement.
The Container Corridor is 100% electrified. The challenges with the electrified sections of the rail network are two-fold, namely energy insecurity and the increasing (high) levels of copper cable theft. Transnet has invested and will continue to invest in back-up power generation in areas of its business most affected, within its financial means.
As indicated during the SONA 2023 address, Transnet must implement the following actions to comply with the approved National Rail Policy:
Introduction of an Infrastructure Manager, independent of the Train Operating Companies by October 2023 is a prerequisite to allow network access for private train operating companies by April 2024, and
Set up the necessary structures and processes to comply with impending regulation of the Infrastructure Management function as set out in the Economic Regulation of Transport Bill.
In accordance with the terms of the Operating Lease agreement that Transnet will enter into with the private sector partner, it will allow Transnet to ensure operating and efficiency standards are maintained with requisite penalties for non-performance. The Infrastructure Manager will be responsible for ensuring compliance with the conditions of the lease.
Notwithstanding the above, the Board of Transnet will review the appropriate responses to the challenges of the container corridor.
Remarks: Reply: Approved / Not Approved
Jacky Molisane P J Gordhan, MP
Acting Director-General Minister of Public Enterprises
Date: Date:
04 October 2023 - NW2529
Hendricks, Mr MGE to ask the Minister of Finance
(1)Whether, in light of the statement made by the Commissioner of the SA Revenue Service (SARS) acknowledging that illicit financial flows (IFF) must be addressed, he will revive the department that dealt with cases of IFF, but was closed by his predecessors; if not, why not; if so, what are the relevant details; (2) whether he intends directing the monies recovered from IFF to ensuring that all South Africans have a right to water and not only access; if not, what is the position in this regard; if so, what are the relevant details; (3) whether he will (a) give SARS greater capacity to hold persons accountable for IFF and (b) allow more effective engagement between government institutions like the National Prosecuting Authority, Financial Intelligence Centre and SARS, with the objective to bring about greater capacities and integration to implement mechanisms for transparency amongst them; if not, why not; if so, what are the relevant details?
Reply:
1. In line with the findings and recommendations of the Nugent Commission of Inquiry, SARS has implemented an improved integrated and collaborative enforcement approach to address issues related to Illicit Financial Flows (IFFs). Various units operating collaboratively have been established to provide a credible response to the threat/risk brought about by IFFs in line with the SARS strategy, to make it hard and costly for taxpayers and traders who do not want to comply. They include:
- STCC, which deals with Syndicated Tax and Customs Crime;
- CI, which deals with criminal investigations involving tax and customs crimes;
- LBI dealing with Large Business and International;
- PIRE dealing with Priority Individuals and Related Entities;
- HWI dealing with High Wealth Individuals and;
- Specialised Audit.
2. All allocations are determined as part of the budget process. If a court decides that recovered money must go into the Criminal Assets Recovery Account (CARA), then funding is allocated in terms of Section 69A of the Prevention of Organised Crime Act of 1998 (POCA) that provides for the allocation of funds to law enforcement agencies and organisations rendering assistance in any manner to victims of crime.
Section 65 of POCA establishes a Criminal Assets Recovery Committee (CARC), which is responsible for providing Cabinet with recommendations on the utilisation of money deposited into CARA and providing advice on specific issues related to the criminal assets recovery process. It consists of the Ministers of Justice and Correctional Services (MoJCS - Chairperson), Police and Finance, the National Director of Public Prosecutions, and, if necessary, two other persons designated by the MoJCS.
3. (a) SARS, like any other entity/department which requires funding from the fiscus, participates in the budget process through which funds are allocated for different priorities and programmes of government.
(b) In 2019, SARS established the Liaison Unit with the aim to strengthen whole-of government collaboration but, particularly, with the law enforcement agencies, the FIC, the AFU, and SARB. This includes:
- Exchanging taxpayer and customs information lawfully;
- Collaboratively executing investigations and prosecutions;
- Sharing resources like people, data, and technology to enhance efficient and effective expenditure by agencies in support of national compliance generally and tax compliance in particular.
04 October 2023 - NW2619
Montwedi, Mr Mk to ask the Minister of Finance
What is the total number of transactions that have been concluded since the launch of the blended finance with the Landbank in October 2022, (b) for which commodities were the transactions and (c) what are the reasons that there have been delays in finalising incomplete transactions, including those of acquiring livestock farms?
Reply:
a) What is the total number of transactions that have been concluded since the launch of the blended finance with the Land Bank in October 2022?
The total number of approved transactions as at 31 Aug 2023: 71
Total value of approvals as at 31 Aug 2023: R591.3 million (R279.9 million of loans, and R311.4 million of grants)
Total disbursements amount as at 31 Aug 2023: R153 million (R77 million of loans, and R76 million of grants)
b) For which commodities were the transactions?
Commodities of Approved Transactions as at 31 August 2023 |
|
Avocados |
Nuts (Macadamia and pecan nuts) |
Bananas |
Poultry |
Dry Beans |
Raisins |
Citrus |
Sugarcane |
Grains and Oilseeds |
Table Grapes |
Livestock (Red meat) |
Vegetables |
(c) What are the reasons that there have been delays in finalising incomplete transactions, including those of acquiring livestock farms?
(i) Reasons for delays in finalizing applications |
1. Clients not submitting all the required application information simultaneously. The quality and accuracy of business and financial information contributes to the waiting time during which the processing of the transactions are paused until all the critical information is submitted. |
2. Applications not viable and financial projections indicative of the business’s inability to service the loan – at times this leads into the submissions being reworked by the clients. |
3. Lack of adherence to environmental and regulatory requirements such as environmental impact assessments, sufficient water volumes and water licenses. These issues generally take long to resolve, and are handled externally by the client through the relevant government departments. The application cannot be finalised without these matters being confirmed. |
4. Poor credit records where clients need to resolve defaults and judgements prior to the application being taken forward. |
5. Insufficient grazing capacity or applications with overgrazing where access to additional parcels of land are not easily accessible. The application will therefore be delayed as a result. |
6. Intermittent capacity constraints and high volume of applications. Some of the Bank’s provincial offices were constrained to turn the transactions around at speed due to vacancies that are currently being field. |
(ii) Delays in processing disbursements |
|
04 October 2023 - NW2733
Cachalia, Mr G K to ask the Minister of Public Enterprises
Whether, with regard to the reported irregularities in tender procurement at Tutuka Power Station that is still under investigation 19 months after the whistle-blower first lodged the complaint (details furnished), he and his department will perform their mandated duty of governance assurance and performance by intervening in the matter, escalating the investigation into irregularities at Tutuka, and keeping track of the progress of the complaint; if not, what is the position in this regard; if so, what are the relevant details?
Reply:
ESKOM REPLY:
In January 2022, Eskom’s Forensic and Anti-Corruption Department received a complaint via email from an anonymous whistle-blower, which highlighted concerns regarding a procurement transaction for Electrostatic Precipitators (ESP) at Tutuka Power Station.
A detailed preliminary investigation was conducted, and the preliminary findings revealed that the matter warrants a full investigation. The matter is currently outsourced to an external service provider, and it is envisaged that the investigation will be completed by the end of November 2023. Eskom will share the findings and recommendations of the investigation with the DPE. If the investigation uncovers fruitless and wasteful expenditure, Eskom will initiate proceedings to recover losses. Eskom will also further engage with law enforcement agencies if any criminality is uncovered.
DPE REPLY
The department has a process in place to oversee that recommendations emanating from forensic reports are implemented. The department shall monitor that the commitment made by Eskom to finalise the investigation. Accordingly, the department shall apply itself to the report to ensure that all recommendations are fully implemented should the allegations be confirmed; and that relevant parties are held accountable in line with the laws of the country. Furthermore, the department shall through the Shareholder Compact, hold the board accountable in ensuring that whistle-blower reports Eskom receives are addressed speedily; that forensic investigations are initiated and completed within a reasonable timeline and that recommendations are fully implemented within reasonable timelines.
Remarks: Reply: Approved / Not Approved
Jacky Molisane P J Gordhan, MP
Acting Director-General Minister
Date: Date:
04 October 2023 - NW2835
Cachalia, Mr G K to ask the Minister of Public Enterprises
What (a) has he found to be the impact of the growth of small-scale embedded generation on electricity sales to municipalities (details furnished) and (b) is the strategy of Eskom’s distribution entity to ensure profitability when municipal demand for Eskom distributed electricity continues to decline due to the appeal of private solar generation?
Reply:
Recently released data by Eskom suggests that from March 2022 until the first quarter of 2023, the amount of electricity generated by Small-scale Embedded Generation (SSEGs), in the form of solar panels, has risen 350%. This increase in reliance on renewable energy is a welcome development for the environment, but poses a significant challenge to municipalities, which derive the majority of their income from electricity sales. Figures from Buffalo City Metropolitan Municipality reveals that SSEGs have cost the municipality R350 million in electricity sales.
The City of Cape Town is currently at the forefront of exploiting this situation for maximum public benefit, by implementing feed-in tariffs, which pays private owners of SSEGs for electricity redirected into the grid, which can then be sold to other consumers at a profit. Energy experts suggest that feed-in tariffs, along with the installation of smart-meters, are the most feasible strategy to overcome the potential losses to municipal income. Much of the Energy Action Plan’s recent (although questionable) successes hinge upon a decline in electricity demand. Reliance on SSEGs significantly drive down demand, and therefore also account for progress made in the fight against nation-wide load shedding.
(a)
The uptake for embedded generators including small-scale systems like rooftop photo voltaic (PV) systems, has been driven largely by customers seeking alternative energy sources due to loadshedding, followed by those wanting to buffer against the upward annual electricity tariff trends, and those that are pursuing greener options aligned with climate change objectives.
The current year’s uptake has been further accelerated by incentive programmes like the SARS tax rebates, attractive distributor feed-in-tariffs as is the case with the City of Cape Town, and the National Treasury energy bounce-back loan guarantee scheme making funding more accessible.
The uptake of small scale embedded generators (SSEGs) has resulted in the displacement of traditional grid-supplied energy volumes. The Eskom Transmission System Operator has established models that estimate the installed capacity of PV on the national grid (i.e. include the SSEGs but exclude government independent power producer programmes) to be 4 841 MW at the end of August 2023 which is estimated to be 2 500 MW more than the previous 12 months window. This translates into an erosion of 2.3% (4.5TWh) of the sales base and 1% (R3.3bn) erosion in the margins (i.e. retail revenue less wholesale purchases) in the window period. The uptake is on an upward trajectory and the Gauteng Province is the largest adopter of SSEGs in the country.
(b)
Eskom Distribution pursues an SSEG framework that is attractive to customers and will ensure network safety, recovery of network costs through unbundled tariffs, retention of customers with new grid services (i.e., net-billing, wheeling and banking) and will offer the Standard Offer Programme which is a form of Feed-In-Tariff that seeks to procure customers’ electricity generation in a competitive manner.
Customers with SSEG installations realise a reduction of about 39% on their overall electricity bill, which translates into a 21% impact on the Eskom margin (i.e. retail revenue less wholesale purchases). This impact on margins is projected to improve from a 21% decline to an 18% decline on average through grid services revenue generated via administration charges (i.e. use of system, offsetting and banking) and ancillary charges.
As the penetration of SSEGs increase, it will necessitate a more dynamic Distribution System Operator (DSO) capabilities to manage supply and demand in real-time through the trading of flexibility energy services (FES) and virtual power plants (VPP).
While there are mechanisms to contain revenue and margin decline due to lost sales and volumes resulting from SSEGs, there are plans to enable and harness the DSO and trading capabilities to offset these revenue losses into the evolving energy future.
Remarks: Approved / Not Approved
Jacky Molisane PJ Gordhan, MP
Acting Director-General Minister
Date: Date:
04 October 2023 - NW2837
Cuthbert, Mr MJ to ask the Minister of Higher Education, Science and Innovation
What amount of (a) historical student debt is currently stated in the financial accounts of the National Student Financial Aid Scheme (NSFAS), excluding that which has been proscribed or written off, (b) the specified debt has been settled with NSFAS and (c) the debt has been written off?
Reply:
a) The historical student loan book value:
As at year ended 31 March 2022, the nominal value of the student loan book was R41.0bn (2021: R40.3bn). The net/carrying value of the student loan book, after considering the adjustments in respect of the actuarial valuation, is R5.1bn (2021: R6.4bn).
b) Debt that has been settled:
During the year ended 31 March 2022 the entity recovered R303m (2021: R388m). The recoveries including debtors that has partially and fully settled their NSFAS debts.
c) Debt written off:
Write offs during the year ended 31 March 2022 because of debtors being deceased amounted to R120m (2021: R114m). This is included in the total aggregated valuation adjustments processed.
04 October 2023 - NW2644
Arries, Ms LH to ask the Minister of Social Development
What (a) total amount has been lost by the SA Social Security Agency (SASSA) in the past two years due to fraudulent activities where officials of SASSA were involved, (b) amount has been recovered to date and (c) consequence management steps were instituted against the officials who were involved?
Reply:
a) For the period under review, approximately 701 suspected cases of fraud cases were detected, investigated, involving 40 SASSA who were implicated to the potential loss of R50 515 541.34. It is important to note that this figure represents a cumulative potential loss documented for the said period involving various other parties not limited to SASSA officials.
These cases ranged from fraudulent collection of grant funds intended for deceased individuals, the submission of disability grant applications with falsified medical information, and the illicit collection of child support grants.
Of the total suspected cases of fraud detected for the period in question, 698 were finalised while 3 are still under investigation. A total of 37 cases were referred to law enforcement agencies for criminal investigation and prosecution.
The notable surge in detection of fraudulent cases can be attributed to SASSA’s anti-corruption strategy.
b) Disciplinary processes in the public service are guided by Chapter 7 of the SMS Handbook (March 2021) as well as the Disciplinary Code (Resolution 1 of 2003). Several sanctions may be issued such as warning letters, suspension, demotion etc. However; the regulations preclude financial recovery of a loss which occurred as a result of fraud that may have arisen through the conduct of the official.
c) The table below provides information on consequence management:
REGION |
NUMBER OF CASES |
CONSEQUENCE MANAGEMEMENT MEASURES IMPLEMENTED AGAINST IMPLICATED OFFICIALS AND SANCTIONS |
Eastern Cape |
19 |
4 x Withdrawn 3 x Pending 1 x Not Guilty 1 x Demotion + Final Written Warning 2 x Suspension without pay + Final Written Warning 8 x Written Warning |
Free State |
3 |
2 x Pending 1 x Written Warning + Referral to Employee Assistance Programme |
Gauteng |
3 |
2 x Dismissal 1 x Written Warning (Informal discipline) |
KwaZulu Natal |
15 |
10 x Pending 2 x Final Written Warning 1 x Dismissal 1 x Written Warning 1 x Not Guilty |
Limpopo |
10 |
1 x Withdrawn 5 x Suspension without pay + Final Written Warning 1 x Dismissal 1 x Demotion + Final Written Warning 1 x Not Guilty 1 x Resigned |
Mpumalanga |
17 |
1 x Written warning 9 x Final Written Warning 7x pending |
North West |
5 |
1 x Withdrawn 1 x Written Warning 2 x Financial Written Warning + Counseling 1 x Suspension without pay + Final Written Warning |
Northern Cape |
2 |
2 x Suspension without pay + Final Written Warning |
Western Cape |
10 |
1 x Written Warning 9 x Pending |
Disciplinary actions were instituted against 74 officials, and 10 officials. Sanctions vary from written warning to dismissal. A total number of 62 cases have been finalised and 22 are in progress. It should also be noted that some fraud cases are being investigated or handled by external or third parties like SIU, Public Protector, National Treasury and SAPS.
04 October 2023 - NW2581
Hlongo, Ms AS to ask the Minister of Social Development
What are the relevant details of the (a) intergovernmental strategies to assist and support homeless persons who are without proper documents such as identity documents or proof of residence to benefit from grants and (b) policy framework to support homeless persons?
Reply:
a) In line with Section 27 of the Constitution of the Republic of South Africa, the Social Assistance Act makes provision for all eligible persons to receive the necessary support in the form of social grants. SASSA has a national footprint, and any homeless person can approach the Agency personally to apply for social assistance. Non-Profit Organisations supporting homeless people could also direct them to SASSA offices for assistance.
The Department is in the process of establishing a Joint Technical Working Team, comprising of the Department of Home Affairs and SASSA to deal with identity documents challenges for social grant beneficiaries, including people living and working on the streets. A 2-year strategy is being developed that will enable the three institutions to work jointly to expedite birth registration and or ID applications of all beneficiaries on the alternative identity system.
b) The process of developing the policy on homeless has commenced guided by the diagnostic study on homelessness. The Draft Policy is envisaged to be in place by the end of the current financial year (2023/24). The consultation process will commence during 2024/2025.
04 October 2023 - NW2908
Abraham, Ms PN to ask the Minister of Finance
Whether he intends to continue financing and expanding public employment programmes such as the Expanded Public Works Programme and the 2021-22 Presidential Employment Stimulus programme over the medium-term expenditure framework; if not, why not; if so, what are the relevant details?
Reply:
Considerations for continued financing and expanding of public employment programmes such as the Expanded Public Works Programme and the Presidential Employment Stimulus programme are part of such the budget process, and the outcome of this process will be announced in the 2023 Medium Term Budget Policy Statement.
04 October 2023 - NW2839
Smalle, Mr JF to ask the Minister of Finance
(1)What (a) are the reasons that the National Treasury stopped the R2.7 billion transfers of conditional grants for the current financial year and (b) is the breakdown of the types of grants that were (i) affected and (ii) effected; (2) what criteria were used to determine which municipalities were negatively affected by the specified grants; (3) whether the affected municipalities will be considered for the next financial year; if not, why not; if so, what are the relevant details; (4) what is the relevant detailed report of the affected municipalities?
Reply:
(a) National Treasury initiated the process of stopping and re-allocation at the end of the second quarter of the 2022/23 municipal financial year, 31 December 2022 and conducted an analysis of the conditional grants performance.
The reasons that informed National Treasury to stop R2.7 billion transfers of conditional grants are:
- Anticipation that a municipality shall substantially underspend the allocation or any programme; and
- Serious or persistence material breach of the Division of Revenue Act.
This decision was considered to safeguard the allocations against possible misuse of the funds and prevent funds from being utilised for operational activities.
1. (b) (i) The grants that were affected are:
Capital grants:
- Water Services Infrastructure Grant 5B;
- Regional Bulk Infrastructure Grant 5B;
- Public Transport Networks Grant (PTNG);
- Urban Settlements Development Gran
- Informal Settlements Upgrading Partnership Grant;
- Neighbourhood Development Partnership Grant 5B
- Integrated National Electrification Programme 5B;
- Municipal Infrastructure Grant; and
- Integrated Urban Development Grant.
Capacity Grants:
- Rural Roads Asset Management System; and
- Energy Efficiency and Demand-Side Management Grant.
- (b) (i) The effect of the stopped funds are:
- The affected municipalities would not be able to implement their full budgeted plan against their programmes;
- Municipalities have to reprioritise the remaining funds against committed and shovel ready projects;
- National Treasury has an opportunity to reallocate the stopped funds (The entire R2.7 billion was reallocated to fast spending programmes between best performing municipalities) to other fast-moving projects in other municipalities; and
- Persistent non-compliance to the Act and anticipated underspending implies that transferred funds may lead to fiscal dumping and possible conditional grants misuse
2. National Treasury used the second quarter reports (Section 71 of MFMA) for the period ending 31 December 2022 and the monthly DoRA reports (Section 10 of 2022 DoRA) received from the transferring officers as a benchmark to decide on municipalities that are underperforming against their allocations.
A benchmark between 40 and 45 per cent against the total allocation was used in determining the list of the proposed municipalities which were considered for stopping after six months into the financial year.
3. The stopping process in terms of Section 18 of DoRA is purely performance based. This section stipulates that National Treasury may in its discretion or at the request of a transferring officer stop the transfer of schedules 4, 5 or 6 allocation if it is anticipated that a municipality shall substantially underspend on the conditional grants that are partially or fully funded by the allocation in the respective financial year.
National Treasury invokes the stopping and reallocation section in the DoRA on an annual basis as part of the monitoring work on the performance of municipalities. When this opportunity arises, municipalities that have improved on their performance and have lost their fund previously are given preference on the reallocation of the allocation in terms of section 19 of DoRA.
4. The National Treasury used the second quarter reports (Section 71 of MFMA) for the period ending 31 December 2022 (mid-year) and the monthly DoRA reports (Section 10 of 2022 DoRA) as submitted by Transferring Officers (national departments administering conditional grants). These reports were used to determine, which municipalities were underspending against their conditional grants and earmarked for stopping of a portion of their conditional grants, i.e., municipalities that had expenditure of less than 40 per cent (for municipalities with allocations of less than R100 million) and 45 per cent (for municipalities with allocations of more than R100 million) of their allocations as at mid-year of the 2022/23 municipal financial year.
04 October 2023 - NW2609
Komane, Ms RN to ask the Minister of Higher Education, Science and Innovation
(a) As at the latest specified date, to which institutions did the National Student Financial Aid Scheme deploy teams in order to assist students to verify themselves so that they may receive funds that were placed on hold because of incomplete verification, (b)(i) on what date and (ii) for how long are the specified teams on campuses to assist students and (c) what number of students have been assisted as at the latest specified date in resolving their issue?
Reply:
TVET COLLEGES
a) The direct payment process was introduced at TVET colleges in the last quarter of 2022, with the first payment made in November 2022, although engagements had started in September 2022. The 2023 academic year saw a continuation of this allowance payment method across all 50 TVET colleges.
To fully support the students with this new direct payments process, during the January / February student registration period, the TVET institutional support team, through the NSFAS Servicing Administrators, conducted working visits at their assigned institutions. During this period, the NSFAS team spent a month deployed in the regions, from 16 January 2023 to 17 February 2023. After this period, there has been instances where some colleges have been visited on an ad hoc basis dependent on what issues the college was facing.
b) (i) Most recently the NSFAS Team was deployed to TVET colleges for the purposes of assisting with challenges, including direct payments, from Monday 18 September 2023 to Friday 22 September 2023.
(ii) The teams were at the colleges for a period of a week.
c) Number of students who ultimately successfully completed KYC as a result of this week cannot be specified, as the KYC process takes place on the direct payment partner platform.
UNIVERSITIES
a) Preparing for the direct payments made for July 2023 allowances, NSFAS initiated a comprehensive process. Initially, NSFAS working with the direct Payment partner began by actively collaborating with institutions and the Student Representative Council (SRC) to define the procedural steps and address any queries or concerns they might have had. Subsequently, during the Month of July and August 2023 NSFAS dispatched resources to these institutions, providing valuable assistance during the onboarding process and offering timely responses to any inquiries that arose.
b) I) Continuing in its commitment to streamline the payment process, NSFAS, in conjunction with its direct payment partners, maintains ongoing engagement with institution management and the SRCs. This proactive approach ensures that any identified issues are promptly addressed. Whenever necessary for NSFAS to visit institution, additional resources are deployed to work closely with institutions, in ensuring that all outstanding matters are effectively resolved by NSFAS and the direct payment partners.
ii) It is not possible to specify the exact number of students who successfully completed the Know Your Customer (KYC) process this week, as the KYC procedure occurs on the direct payment partner's platform.
04 October 2023 - NW2848
Abrahams, Ms ALA to ask the Minister of Social Development
(1)Whether the shortage of client-facing staff and resources is the true reason for not reintroducing the service of bringing the SA Social Security Agency (SASSA) services to communities via community halls (details furnished); if not, what are the reasons that the SASSA no longer offers the specified service; if so, what are the relevant details; (2) by what date will (a) SASSA fill the many client-facing level vacancies at local offices, (b) communities expect the reintroduction of the services within the nine provinces and (c) SASSA (i) communicate and (ii) advertise a rotational roster including dates, times and venues for the service to communities?
Reply:
1. SASSA suspended outreach programmes during the outbreak of the COVID-19 pandemic in line with the national state of disaster regulations. Subsequent to the lifting of the COVID-19 restrictions in 2021, SASSA gradually commenced with restoring all direct client services. To date, the Integrated Community Registration Outreach Programme (ICROP) is being implemented by local offices in all nine provinces.
2. Refer to Annexure A
(a) The government wide cuts to the Compensation of Employees (COE) budgets across Government has adversely the filing positions within SASSA. SASSA continues to prioritise the filling of funded posts, with specific focus on front- line staff (based at local offices) with the limited resources allocated each financial year. SASSA is also looking at innovative ways (including digitisation of certain functions) to reduce the demand for direct interaction with clients. In addition to this, it is important for the Honourable to note:
- Currently there are 7 433 posts filled. Of this number, 4 994 (67%) of the are based at local office layer, which forms part of the front-line staff;
- Filling of some of the posts has been put on hold due to the Business Process Re-Engineering currently underway. This might result in the adoption of a new organisational structure in line with the strategic plan.
- The National Treasury’s Cost Containment Circular directs all departments and agencies, SASSA included, to absorb the wage bills from their respective allocation of the Compensation of Employees budget.
(b) Refer to (a) and (b) above.
(c) Refer to 1 above. The implementation of ICROP is ongoing and SASSA utilises local media, including community radio stations and tribal councils to inform local communities.
- Breakdown of the filling of posts within the Local Offices in each SASSA Regional Office:
REGION |
2020/2021 FY |
2021/2022 FY |
2022/2023 FY |
2023/2024 FY
|
|||||||||
FILLED LOCAL OFFICE POSTS |
APPROVED FUNDED VACANCIES - LOCAL OFFICE |
TERMINATIONS |
FILLED LOCAL OFFICE POSTS |
APPROVED FUNDED VACANCIES - LOCAL OFFICE |
TERMINATIONS |
FILLED LOCAL OFFICE POSTS |
APPROVED FUNDED VACANCIES - LOCAL OFFICE |
TERMINATIONS |
FILLED LOCAL OFFICE POSTS |
APPROVED FUNDED VACANCIES - LOCAL OFFICE |
RECOMMEDED (STILL TO BE APPROVED) |
TERMINATIONS |
|
EC |
875 |
14 |
47 |
885 |
12 |
32 |
885 |
5 |
35 |
867 |
3 |
11 |
12 |
FS |
336 |
4 |
10 |
306 |
10 |
15 |
311 |
2 |
10 |
302 |
2 |
6 |
4 |
GP |
644 |
13 |
16 |
624 |
5 |
19 |
611 |
4 |
18 |
603 |
3 |
8 |
7 |
KZN |
1148 |
22 |
52 |
1112 |
45 |
26 |
1102 |
4 |
25 |
1095 |
3 |
17 |
8 |
LP |
629 |
16 |
29 |
604 |
12 |
21 |
581 |
5 |
24 |
575 |
4 |
13 |
4 |
MP |
343 |
6 |
9 |
350 |
14 |
4 |
343 |
6 |
8 |
340 |
4 |
6 |
4 |
NW |
464 |
14 |
12 |
453 |
4 |
10 |
437 |
1 |
25 |
434 |
3 |
7 |
2 |
NC |
281 |
7 |
7 |
280 |
14 |
11 |
273 |
10 |
12 |
271 |
4 |
3 |
2 |
WC |
569 |
16 |
24 |
535 |
10 |
11 |
518 |
9 |
18 |
507 |
7 |
3 |
11 |
Grand Total |
5289 |
112 |
206 |
5149 |
126 |
149 |
5061 |
46 |
175 |
4994 |
33 |
74 |
54 |
(b) All services have been restored post COVID.
(c) The schedule for community outreaches are planned with key local stakeholders through the various local stakeholder forums; who also assists with informing the communities on the planned activities. SASSA also conducts “loud hailing” before the outreach.
04 October 2023 - NW2836
Cachalia, Mr G K to ask the Minister of Public Enterprises
(a)What steps will he take through the Business Enhancement and Industrialisation Programme to ensure that the virtual wheeling system can be implemented nationally and (b) how will finances be arranged to implement the smart-meter and cloud system required for the project?
Reply:
Wheeling refers to a regime where private generators are allowed to sell directly to eligible customers by signing a use of system agreement with the transmission and distribution network owners. For eligible customers connected to the Eskom network, the process for entering into a wheeling agreement requires an amendment to the customer’s existing supply agreement with Eskom, which will allow the customer’s electricity bill to be adjusted (to be credited) to take account of wheeled energy. This type of wheeling requires an amendment to the customer’s existing supply agreement is called traditional wheeling, and it is limited to connections on the high voltage and medium voltage networks.
Virtual wheeling, however, eliminates the need for amendments to supply agreements and expands wheeling to customers connected at low voltage networks. This enables entities like banks, hotels, corporate offices, and retailers to wheel energy from private generators.
Virtual wheeling is designed to work alongside traditional wheeling arrangements, not replace them. Additionally, Eskom will contract the buyer of energy directly, without the need to contract with off-takers (load customers), including municipalities. As a result, there will be no impact on municipal revenue, and this distinguishes virtual wheeling from the traditional wheeling approach.
Currently, the project will be executed on a pilot basis between Eskom and Vodacom to enable Eskom to test the systems and resource capabilities before the official country wide roll-out.
The smart meters and cables that will be required by buyers and offtakes of electricity are already supported by a local market.
(b)
There is no requirement for municipalities to invest in large-scale systems and cloud servers. Eskom will invest in a digital tool known as a virtual wheeling platform to facilitate the virtual wheeling and this will integrate with buyer platforms. This wheeling platform is required to support the aggregation, processing and provision of generation and consumption data to calculate the wheeled energy refund.
Virtual wheeling requires the measurement and reporting of energy generated and consumed on a time-of-use basis and this is allocated by buyers of electricity to their off-takers. All off- takers will need to be equipped with the necessary meters capable of supporting these functions. The investment will need to be made by the buyers and/or off-takers (load customers) and not municipalities.
Remarks: Approved / Not Approved
Jacky Molisane PJ Gordhan, MP
Acting Director-General Minister
Date: Date:
04 October 2023 - NW2879
Herron, Mr BN to ask the Minister of Finance
(1)Whether, considering that in terms of the Municipal Fiscal Powers and Functions Act, Act 12 of 2007, a municipal base tariff includes a reasonable rate of return if authorised by a regulator and/or the Minister responsible for the municipal service, and whereas the National Energy Regulator of South Africa is the regulator for electricity services and that the annual approval of electricity tariffs levied by municipalities includes the reasonable rate of return or surplus margin, the City of Cape Town also charges a municipal surcharge on top of its electricity tariffs called a contribution to rates or an unregulated charge, he has prescribed compulsory norms and standards for municipal surcharges on electricity services as provided for in section 8 of the specified Act; if not, what is the position in this regard; if so, (a) on what date(s) were the norms and standards prescribed and (b) will he furnish Mr B N Herron with a copy of the norms and standards; (2) whether he has found that the City of Cape Town complied with the norms and standards as required by section 9(1)(a) of the Act; if not, what is the position in this regard; if so, what are the relevant details; (3) whether the City of Cape Town, on its own and/or as part of a group of municipalities and/or organised local government, applied for and was granted an exemption from compliance with the norms and standards as provided for in terms of section 9(1)(b) of the Act; if not, what is the position in each case; if so, (a) on what date did he gazette the exemption and (b) will he furnish Mr B N Herron with a copy of the notice in the Gazette; (4) whether he promulgated any regulations in terms of the Act, which provide for the municipal surcharge on electricity services currently levied by the City of Cape Town; if not, what is the position in this regard; if so, what are the relevant details; (5) (a) in terms of which provisions of the Act and/or any other applicable law is the City of Cape Town authorised to charge a municipal surcharge on electricity services and (b) what are the consequences to the City of Cape Town for charging a levy on a municipal surcharge on electricity services without being authorised by himself and/or the Act
Reply:
(1) Section 8(1) of the Municipal Fiscal Powers and Functions Act (MFPFA) stipulates that the Minister of Finance may prescribe compulsory norms and standards for imposing municipal surcharges. To date, the Minister of Finance have not prescribed any compulsory norms and standards for regulating the imposition of municipal surcharges. However, the absence of the norms and standards does not restrict a municipality from imposing surcharges in their tariffs given that this is a power given to municipalities in terms of section 229 of the Constitution and the Municipal Systems Act (MSA). Furthermore, if a municipality decides to levy a surcharge, approval is done by the municipal council in terms of a tariff policy, pursuant to section 75 of the MSA and will also be subject to section 8 of the Municipal Fiscal Powers and Functions Act (MFPFA), as soon as norms and standards for municipal surcharges are prescribed by the Minister of Finance. The National Treasury is currently reviewing the possibility of introducing compulsory norms and standards in terms of section 8 of the MFPFA and has appointed a service provider to assist with the development of compulsory national norms and standards for regulating municipal surcharges on electricity.
- Not applicable.
- Not applicable.
(2) It is not yet necessary for the City of Cape Town (or any other municipality) to comply with section 9(1) of the MFPFA given that the norms and standards referred to in section 8 of the Act is yet to be prescribed by the Minister of Finance. As soon as these norms and standards are prescribed, all municipalities levying surcharges on municipal services will however be required to comply with this provision.
(3) See response in (2).
- Not applicable.
- Not applicable.
4. See response in (1).
(5)(a) Various pieces of legislation regulate the levying of municipal surcharges:
The Constitution
Section 229 of the Constitution indicates that a municipality may impose—
(1) subject to subsections (2), (3) and (4), a municipality may impose
(a) rates on property and surcharges on fees for services provided by or on behalf of the municipality
(2) The power of a municipality to impose rates on property, surcharges on fees for services provided by or on behalf of the municipality, or other taxes, levies or duties—
(b) may be regulated by national legislation.
The Municipal Fiscal Powers and Functions Act (MFPFA)
Section 8 of the MFPFA gives power to the Minister of Finance to prescribe compulsory national norms and standards for imposing “municipal surcharges”. Furthermore, when levying surcharges, municipalities are required in terms of section 9(1)(a) of the MFPFA to comply with any norms and standards contemplated in section 8 of the MFPFA.
The Municipal Systems Act (MSA)
Section 4(1)(c)(ii) of the MSA indicates that the council of a municipality has the right to finance the affairs of the municipality by imposing surcharges on fees, rates on property and, to the extent authorised by national legislation, other taxes, levies and duties. In section 74(2)(f), the Act provides that a municipal tariff policy must reflect at least the following principles: “(f) provision may be made in appropriate circumstances for a surcharge on the tariff for a service”. In terms of section 94(1), the Minister responsible for Local Government may regulate the following matters: “(d) criteria to be taken into account by municipalities when imposing surcharges on tariffs for services and determining the duration thereof;”.
(b) Once norms and standards for municipal surcharges are prescribed for a specific municipal service as per section 8 of the MFPFA, any municipality that does not adhere to such norms and standards (e.g. exceeds prescribed levels) will be in non-compliance with the Act, except if the Minister of Finance has given approval to such municipality in terms of section 9(1)(b) to be exempted from complying to any of the norms and standards as contemplated in section 8 of the Act.
04 October 2023 - NW2752
Faber, Mr WF to ask the Minister of Public Enterprises
What total amount did (i) his department and (ii) each entity reporting to him pay for printed copies of the integrated annual reports (aa) 2020-21, (bb) 2021-22 and (cc) 2022-23 financial years, (b) who were the suppliers in each case and (c) what total number of copies of the report were printed (i) in each case and (ii) in each specified financial year?
Reply:
Department of Public Enterprises
(a)
(i) (aa) The cost for Annual Report 2020-21 F/Y was R62 504.80. This amount was for design, layout, editing, proofreading and printing of 100 copies as well as 2 USB format.
(b) Fineart Printers
(c) 100 printed copies
(bb) The cost for Annual Report 2021-22 F/Y was R 69 080.00. This amount was for design, layout, editing, proofreading and printing of 100 copies as well as 2 USB format.
(b) PulseMag
(c) 100 printed copies
(cc) The cost for Annual Report F/Y 2022-23 F/Y is an estimate at +R70 000. 00. As the number of pages and print run has not yet been finalized.
(b) Pulsemag
(c) 100 printed copies
According to Information Received from SOCs
ALEXKOR SOC LIMITED:
(a)(ii)(aa) 2021-22: The integrated report (IR) was printed in-house for AGM attendees only.
(bb) 2021-22: The external audit was delayed due to the decision to request the AGSA to opt-in. The audit opinion for this reporting period was presented to the Board on 31 August 2023 and the IR will be printed in-house for AGM attendees before the end of September 2023.
(cc) 2022-23: An extension was granted for the submission of the AFS and IR for external audit to 31 August 2023. The IR will be printed for AGM attendees upon completion of the external audit.
(b)(aa) 2020-21: Nexus Sustainability (Pty) Ltd provided editing services to Alexkor SOC for R81 909.00 which was not inclusive of printing.
(bb) 2021-22: The IR will be printed in-house.
(cc) 2022-23: The IR will be printed in-house.
(c)(aa) 2020-21: 10 copies were printed.
(bb) 2021-22: Not yet printed.
(cc) 2022-23: Not yet printed.
DENEL SOC LIMITED:
(a)
(ii) Kindly note that the finalisation of Denel SOC Ltd Annual Reports has been delayed due to liquidity constraints. No Integrated Annual Reports for the said financial periods have been finalised and printed yet.
(b) The supply chain process to appoint a service provider is still underway.
(c) No Integrated Annual Reports for the said financial periods have been finalised and printed yet.
ESKOM SOC LIMITED:
a) (ii) Eskom has incurred the following costs for printed copies of its annual reports for the financial years shown below:
Annual reports for the year ended |
31 March 2021 |
31 March 2022 |
31 March 2023 |
Integrated Report |
R91 517.64 |
R96 554.61 |
R107 070.30 |
Annual Financial Statements |
R73 892.94 |
R91 672.39 |
R78 602.40 |
Sustainability Report |
R17 966.67 |
R19 142.44 |
R23 054.40 |
Total cost (excluding VAT) |
R183 377.25 |
R207 369.44 |
R208 727.10 |
Note: In each case, the annual reports are printed and published in the subsequent financial year (i.e., annual reports for the year ended 31 March 2022 were printed and published in the 2023 financial year).
Eskom has not yet published its annual reports for the year ended 31 March 2023 and therefore has not incurred any related printing costs. The budgeted amount has been shown instead.
b) The supplier contracted for design, typesetting, proofreading, and printing of the annual reports for the years ended 31 March 2021 and 31 March 2022 was HKLM Hlapa JV (Pty) Ltd. The printing services were subcontracted to Law Printing (Pty) Ltd (Lawprint).
The reports for the year ended 31 March 2023 will be produced by Ince (Pty) Ltd.
c) The total number of copies printed for the annual reports are as follows:
Annual reports for the year ended |
31 March 2021 |
31 March 2022 |
31 March 2023 |
Integrated Report |
205 |
205 |
200 |
Annual Financial Statements |
210 |
210 |
200 |
Sustainability Report |
55 |
55 |
50 |
Total number of copies |
470 |
470 |
450 |
SAFCOL SOC LIMITED:
a) The total amount by entity
(aa) 2020-21 |
(bb) 2021-22 |
(cc) 2022-23 |
|
(i) N/A |
|||
(ii) SAFCOL |
R46 806,88 |
R51 134,29 |
R54 713,69 (estimate) |
The service provider was appointed for a period of three years; the total contract value is R1 457 775,82. The Financial year 2022-23 amount is an estimate because page numbers are not finalised nor has the print run been confirmed but it’s included based on last year's amount. The integrated report is being prepared for finalisation soon.
b) Suppliers per financial year
2020 -21 |
2021-2022 |
2022-23 |
SILVAPOD (PTY) LTD |
SILVAPOD (PTY) LTD |
SILVAPOD (PTY) LTD |
c) Total number of copies of the report printed per financial year
2020-21 |
2021-22 |
2022-23 |
200 |
200 |
200 |
SOUTH AFRICAN AIRWAYS SOC LIMITED
For the period 2020 to date, South African Airways (SAA) are still having its final statements audited, as such the airline did not print copies, nor procured the services of a printing company for the printing of its integrated annual reports.
TRANSNET SOC LIMITED
The table below indicates the amounts paid by Transnet for the printed copies of the integrated annual reports and the number of copies printed in each of the financial years under question.
Year |
Service Provider (b) |
Number of copies (c) |
Amount (a) |
(i)and(ii) |
|||
(aa) 2020-21 |
Magnific |
490 |
R225,693 |
(bb) 2021-22 |
Magna Carter Corporate Advisory Services |
490 |
R295,693 |
(cc) 2022-23 |
Ince |
260 |
R169,636 |
Remarks: Approved / Not Approved
Jacky Molisane PJ Gordhan, MP
Acting Director-General Minister
Date: Date:
04 October 2023 - NW2937
Alexander, Ms W to ask the Minister of Finance
Whether, in light of financial losses incurred by municipalities as a result of lower electricity sales due to the rolling blackouts, the National Treasury has taken any steps to assist struggling municipalities to adapt and recalibrate their budgets; if not, what is the position in this regard; if so, what are the relevant details?
Reply:
The Municipal Finance Management Act, 2003 (Act No 56 of 2003) and through various sections of the Act, provide guidelines to municipalities on how to treat impending revenue shortfalls. In addition, the National Treasury also provides regular Budget Circulars to guide municipalities to prepare annual budgets and address situations like loadshedding.
Section 70 of the MFMA, subsection 1. “the accounting officer of a municipality must report in writing to the municipal council – (a) any impending (i) shortfalls in budgeted revenue, and (ii) overspending of the municipality’s budget, and (b) any steps taken to prevent or rectify such shortfalls or overspending.
Section 28 of the same Act provides guidance on Municipal Adjustments Budgets – (1)(a) that “a municipality may revise an approved budget through an Adjustments Budget and (2)(a) must adjust the revenue and expenditure estimates downwards if there is a material under collection of revenue during the current year.
Given the fiscal constrained environment within which the National Fiscus operates, the National Treasury was not in a position during the preparation of the 2022 MTEF, to make any additional funding available to municipalities for this purpose. As a result, they were advised to reprioritize their tabled 2023 MTREF Budgets to absorb the cost associated with loadshedding within baselines.
03 October 2023 - NW2648
van der Merwe, Ms LL to ask the Minister of Home Affairs
(1) How do the counter-return operations of his department that are part of interventions to combat illegal mining, particularly in Gauteng, differ from the traditional border patrol activities of the department; (2) whether the counter-return operations were budgeted for; if not, why not; if so, what are the relevant details; (3) whether additional budget needs to be allocated; if not, what is the position in this regard; if so, what are the relevant details?
Reply:
1. The Justice, Crime Prevention and Security Cluster (JCPS), which the Department is part of and which now also includes the Border Management Authority (BMA), has developed a strategy to deal with countering illegal mining throughout the country. There is special focus on four provinces namely Gauteng Province, North-West Province, Mpumalanga and Limpopo Province due to the history of mining.
2. The counter-return operations include other law enforcement agencies.
3. The JCPS Cluster is working on additional funding requests for counter-return operations.
END
02 October 2023 - NW3012
Powell, Ms EL to ask the Minister of International Relations and Cooperation
(1)What (a) are the details and/or a full list of all political party representatives invited to attend the 2023 BRICS Political Party Plus Dialogue and (b) was the selection criteria used to determine to whom such invitations would be extended; (2) what costs have her department contributed to the (a) BRICS Ministerial Meeting hosted in Cape Town on 1 June 2023, (b) 2023 BRICS Political Party Plus Dialogue hosted on 18 July 2023 and (c) BRICS Summit hosted in August; (3) what are the full and cumulative costs for (a) BRICS Ministerial Meeting hosted in Cape Town on 1 June 2023, (b) 2023 BRICS Political Party Plus Dialogue and (c) the BRICS Summit hosted in August? NW4077E
Reply:
1. (a) The political parties of the respective BRICS Plus countries were invited by South Africa’s governing party, the African National Congress, to attend the BRICS Political Party Plus Dialogue. The South African Government was not involved in organising the BRICS Political Party Plus Dialogue. (b) The South African Government was not involved in the selection nor the extending of invitations to any political party.
2. (a) The Departmental contribution to the BRICS Ministerial of 1st and 2nd June hosted in Cape Town amounted to ZAR 9 848 909.51 (b) The South African Government and the Department of International Relations and Cooperation did not contribute to the BRICS Political Party Plus Dialogue. (c) The Department will only be able to provide information once the reconciliation of accounts has been completed.
3. (a) The full and cumulative costs for the BRICS Ministerial were ZAR 9 848 909.51.(b) The South African Government and the Department did not contribute financially to the 2023 BRICS Political Party Plus Dialogue. (c) The Department will only be able to provide the full and cumulative costs once the reconciliation of accounts has been completed.
02 October 2023 - NW2583
Letsie, Mr WT to ask the Minister of Higher Education, Science and Innovation
In light of the fact that the National Student Financial Aid Scheme has been on the news recently for a number of reasons, one of them being the inability of the recently appointed Fintech companies to distribute allowances to students and allegations of some of them having not met the minimum requirements to be appointed, what has he and his department done to (a) get to the bottom of the allegations and (b) ensure students are not affected negatively from now onwards?
Reply:
a) The Department has studied the allegations against Fintech companies and regards them as very serious. The Department has engaged the NSFAS board on several occasions and is awaiting Werksmans Attorneys’ findings so that any decision taken is guided by verifiable facts and evidence, is lawful, reasonable, and procedurally fair as per legal prescripts derived from our constitution, and related legislation, including the Public Administrative Justice Act of 2000. In addition, the Department has despatched a senior official to be incorporated into the Appeals Committee to assist with tracking progress and developing solutions to arising problems.
b) The Department regrets that some students have been affected by the systems introduced by the Fintech companies. The Department has been advised that NSFAS has sent a team of senior officials to ten of the most affected institutions to engage the students and understand the challenges they are experiencing with the Fintech companies. The team will be concluding their report on 22 September 2023. It is expected that they will numerate all issues, and resolve them with necessary alacrity, including finalising a Change Management Strategy.
02 October 2023 - NW2977
Shaik Emam, Mr AM to ask the Minister of International Relations and Cooperation
What steps has her department put in place to address the concerns that have been raised regarding South Africans of Jewish origin who continue to receive training in the Israeli defence force which poses a serious risk to the Republic?
Reply:
The National Conventional Arms Control Committee (NCACC) administers the Prohibition of Mercenary Activities and the Regulations of Certain Activities in a country of Armed Conflict Act (Act 27 of 2006) that regulate and control matters related to the question posed. However, the competency and responsibility to enforce the law, gather intelligence, investigation and prosecutorial discretion, regarding the breach of the abovementioned laws does not reside with DIRCO but other Government departments such as the Departments of Justice and Constitutional Development, Defence and Military Veterans, State Security and the National Prosecution Authority.
02 October 2023 - NW2953
Shikwambana, Mr M to ask the Minister of Higher Education, Science and Innovation
What (a) steps have sector education and training authorities taken to ensure the successful implementation of skills development outcomes over the past three financial years, (b) total number of (i) programmes have been implemented in the provinces and (ii) beneficiaries have (aa) been trained and (bb) completed the programmes and (c) impact has the programmes brought about in the lives of the beneficiaries in terms of (i) job creation, (ii) the expansion of businesses and (iii) the establishment of new enterprises?
Reply:
a) The core responsibility of a Sector Education and Training Authority (SETA) is to develop a Sector Skills Plan (SSP) as mandated by the Skills Development Act (Act No. 97 of 1998). SETAs facilitate the delivery of sector-specific skills interventions that enable the achievement of the outcomes of the National Skills Development Plan (NSDP) and other applicable policy instruments. Research is critical in this regard, as SETAs are required to conduct research to identify occupations/skills in demand in their respective sectors.
The Department develops (and annually updates) the Sector Skills Plan Framework, guiding the SETAs, which takes into account amongst others, change drivers such as : regulatory and policy issues such as government legislation (i.e. White Paper for Post School Education and Training, National Plan for Post School Education and Training, etc); national and provincial plans which drive growth and development; economic growth or decline in a sector; changes to the nature of work such as changes in technology, work organization, production and process innovation; the business environment such as export markets, consumer preferences, and competitiveness in the market, globalization and others; immigration and emigration and social issues such as poverty, HIV/AIDS, health and safety issues, etc. The SSPs include chapters such as Sector Profile; Key Skills Drivers; Occupational Shortages and Skills Gaps; SETA Partnerships and SETA Monitoring and Evaluation. Other Labour Market Intelligence Instruments such as National List of Occupations in High Demand; Critical Skills List; Economic Reconstruction and Recovery Plan Skills Strategy guide the implementation of skills development interventions. Subsequently, each SETA develops an Annual Performance Plan and Strategic Plan (as tabled in Parliament) and is monitored through the Portfolio Committee on Higher Education, Science and Innovation and other parliamentary processes. Annual Reports are compiled and tabled to Parliament, monitoring the performance of the SETAs. Consequently, the Department as directed by the Skills Development Act (Act No.97 of 1998) also enters into Service Level Agreements with the SETAs.
(b)
Year 2020/21: (b) Total number of programs have been implemented in the provinces and beneficiaries trained and completed programs |
||
Province |
(aa) Beneficiaries trained |
(bb)Beneficiaries completed |
Eastern Cape |
18 944 |
12 500 |
Free State |
7 101 |
5 546 |
Gauteng |
57 167 |
43 038 |
KwaZulu Natal |
22 243 |
18 389 |
Limpopo |
20 384 |
19 805 |
Mpumalanga |
8 862 |
8 804 |
North West |
7 247 |
7 192 |
Northern Cape |
4 787 |
3 835 |
Western Cape |
18453 |
14 620 |
Total |
165 188 |
133 729 |
Year 2021/22: (b) Total number of programs have been implemented in the provinces and beneficiaries trained and completed programs |
||
Province |
(aa) Beneficiaries trained |
(bb)Beneficiaries completed |
Eastern Cape |
28 929 |
13 963 |
Free State |
18 210 |
28 020 |
Gauteng |
60 591 |
43 362 |
KwaZulu Natal |
33 069 |
19 919 |
Limpopo |
20 752 |
14 580 |
Mpumalanga |
12 291 |
9 196 |
North West |
11 422 |
8 649 |
Northern Cape |
5 890 |
4 804 |
Western Cape |
23377 |
15 250 |
Total |
214 531 |
157 743 |
Year 2022/23: (b) Total number of programs have been implemented in the provinces and beneficiaries trained and completed programs |
||
Province |
(aa) Beneficiaries trained |
(bb)Beneficiaries completed |
Eastern Cape |
23159 |
13115 |
Free State |
11630 |
5581 |
Gauteng |
79105 |
46643 |
KwaZulu Natal |
41827 |
21865 |
Limpopo |
27749 |
19929 |
Mpumalanga |
17731 |
10585 |
North West |
9957 |
6951 |
Northern Cape |
8450 |
4061 |
Western Cape |
30531 |
14748 |
Total |
250 139 |
143 478 |
(c)(i) The SETAs and the Department conduct tracer studies, to track the beneficiaries of the SETA skills development interventions on a regular basis, one of these studies was conducted by Rhodes University, and its outcomes are summarised as follows.
One of the key measures of interest in any tracer study of graduates or completers is the employment rate. If the percentages of completers in Workplace Based Learning Programs (WBL) programs in self-employment and employment are added together, the result is an employment rate of roughly 80% for learnership completers and 60% for those who have recently completed apprenticeships. Therefore, the employment rate among the sample of SETA-funded WBL completers is very high. A key difference between the completers of apprenticeship and learnership programs, however, is that a third of apprentices were not working at the time of the survey compared with about 17% of learnership completers. Based on this alone, one conclusion is that learnership programs appear to be more closely associated with a smooth transition into employment. At the same time, only very small numbers of WBL completers reported studying further after the completion of their training program (6% of apprentices and 3% of learnership completers).
WBL completers who are employed, one of the key findings is that nearly all completers (who were employed at the time of the survey) within each WBL program found employment within six months after the completion of their WBL program. There were only slight differences in the percentage of apprenticeship (89.5%) and learnership (96.3%) completers who found employment within a six-month period. In terms of employment characteristics, the findings suggest that apprenticeship completers were more likely (43.6%) to be employed in a permanent position relative to learnership completers (22.3%). The vast majority (58.4%) of learnership completers were employed in fixed-term positions at the time of the survey. While this would suggest that an apprenticeship is a more direct route to stable employment, about 29.3% of apprenticeship completers were in casual employment (compared with just under a fifth of learnership completers). Therefore, while permanent employment was the modal form of employment for the completers of apprenticeships, a substantial group was also in the most unstable type of employment relationship (casual employment).
(c) (ii) Notably, in the tracer study by Rhodes University, is that the share of WBL completers in self-employment is less than one percent. One of the artisan tracer studies conducted by the Department indicated that 2% (whilst 79% were employed) were self-employed. About 15% of those self-employed individuals indicated that they saw an opportunity for self-employment.
(c) (iii) see as referred above.
02 October 2023 - NW2986
Mbabama, Ms TM to ask the Minister of Water and Sanitation
(1)With reference to the draft regulations relating to the Procedural Requirements for Water Use Licence Applications that were published on 19 May 2023, what are the details of the (a) total number of farmers or farming and/or agricultural entities that hold water use licences in accordance with each category of sections 21(a) and (b) and section 21(d) in terms of Table 1 in Chapter 5 of the draft regulations, (b) number of the specified licence holders who hold water use licences and do not meet the equity criteria in each category, in cases where an application had to be made in terms of the specified draft regulations; (2) what number of applications for water use licences from farmers and/or farming and/or agriculture sector entities has her department (a) received and (b) approved to black persons in each category of sections 21(a) and (b) and section 21(d) in the (i) 2019, (ii) 2020, (iii) 2021, (iv) 2022 and (v) 2023 years of assessment?
Reply:
1. (a) There is no application that was submitted in terms of the Draft Regulations Published on 19 May 2023. The Regulations published on 19 May 2023 are not yet implemented because they were issued only for public comments.
(b) Refer to the response above.
(2) The total number of Licences received and issued to HDIs from 2019 – 2023 August is 457.
2019 |
2020 |
2021 |
2022 |
2023 |
84 |
60 |
141 |
117 |
55 |
---00O00---
02 October 2023 - NW2812
De Freitas, Mr MS to ask the Minister of Tourism
(1) With reference to tourism projects (a) in the past three financial years and (b) since 1 April 2023, which specified projects were initiated respectively, and in each case, (i) on what date was each project initiated and (ii) which of the projects were completed and not completed; (2) what are the (a) actual completion dates for each completed project in each case and (b) deadlines by which the incomplete projects were to be concluded in each case; (3) what were the (a) dates on which it was decided that each project was incomplete in each case and (b) reasons for each project not being completed by the set deadline in each case; (4) what total (a) budget was allocated to each incomplete project in each case and (b) amounts were spent on each incomplete project in each case?
Reply:
1 (a) See table below
1 (b) No projects were initiated since 1 April 2023. The projects initiated since 2020/21 financial year are listed in the table below.
2 (a) and (b) - See table below
3 (a) and (b) - See table below
4 (a) and (b) - See table below
Please note
Practical completion – It is a stage of completion as certified by the Professional Service Provider where the work has been completed and is free of patent defects other than minor defects identified in the list for completion. The facility can be used for the intended purpose.
Works completed – Completion of works as per the scope of works and contract and the employer is entitled to possession of the works and site.
Projects |
(1)(i) On what date was each project initiated |
(1)(ii) Which of the projects were completed and not completed |
(2)(a) What are the actual completion dates for each completed project in each case |
(2)(b) What are the deadlines by which the incomplete projects were to be concluded in each case |
(3)(a) What were the dates on which it was decided that each project was incomplete in each case |
(3)(b) What were the reasons for each project not being completed by the set deadline in each case |
(4)(a) What total budget was allocated to each incomplete project in each case (4)(b) What total amounts were spent on each incomplete project in each case |
COMPLETED PROJECTS |
|||||||
Khomani San Interpretative Centre and Narrative Development |
Contract with the Implementing Agent signed in March 2020 |
Completed |
Construction started in June 2021 and was completed in March 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Nwanedi Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Blouberg Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Musina Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Makapans Valley WHS |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Modjadji Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Manyeleti Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Andover Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
SS Skosana Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in June 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Double Mouth Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and was completed in July 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Khayelitsha Lookout Hill |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in December 2022 and was completed in June 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
De Hoop Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in December 2022 and was completed in June 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Wolvekloof Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in December 2022 and was completed in June 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Goukamma Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in December 2022 and was completed in June 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Kogelberg Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in December 2022 and was completed in June 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Oviston Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion). PC was granted on 01.09.2023 |
Construction started in Jan 2023 and was completed in Sept 2023 |
Project completed |
Project completed |
Project was affected by hunting season. Contractor had limited access to site causing delay against the baseline PC date |
Project completed |
Cedarberg Wilderness |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in and was completed in June 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Nyandeni |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in August 2022 and was completed in Aug 2023 |
Project completed |
Project completed |
The initial phase of the project was not completed due to budget shortfall. Project is currently completed through the DBSA contract. |
Project completed |
Western Tembuland Lodge |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Works completion) |
Construction started in July 2022 and completed in June 2023 |
Project completed |
Project completed |
The initial phase of the project was not completed due to budget shortfall. Project is currently completed through the DBSA contract |
Project completed |
Maluti Hiking and Horse Trail |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Works completion) |
Construction started in July 2022 and completed in June 2023 |
Project completed |
Project completed |
The initial phase of the project was not completed due to poor workmanship. Project is currently completed through the DBSA contract. |
Project completed |
Monontsha Access Road |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in September 2022 and completed in September 2023 |
Project completed |
Project completed |
The initial phase of the project was not completed due to budget shortfall. Project is currently completed through the DBSA contract. |
Project completed |
Songimvelo Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in January 2023 and completed in September 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
Thomas Baines Nature Reserve |
Contract with the Implementing Agent signed in Nov 2020 |
Completed (Practical completion) |
Construction started in February 2023 and completed in September 2023 |
Project completed |
Project completed |
Project completed |
Project completed |
WORK IN PROGRESS PROJECTS |
|||||||
Tshahogwe Game Farm |
Contract with the Implementing Agent signed in 2020 |
Construction is about 56% towards completion. |
Construction is in progress |
2023-11-14 |
Completion date not yet due |
Completion date not yet due |
Budget R24,991,978 Exp R8,856,601 |
Mtititi Game Farm |
Contract with the Implementing Agent signed in 2020 |
Construction is about 89% towards completion. |
Construction is in progress |
2023-11-07 |
Completion date not yet due |
Completion date not yet due |
Budget R26,073,422 Exp R13,510,035 |
Mapate Recreational Social Tourism Facility |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 72% towards completion. |
Construction is in progress |
2023-10-03 |
Completion date not yet due |
Completion date not yet due |
Budget: R25,654,359 Exp: R8,640,430,66 |
LP Matsila Lodge |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 55% towards completion. |
Construction is in progress |
2024-01-05 |
Completion date not yet due |
Completion date not yet due |
Budget R40,221,328 Exp R9,289,770 |
Nandoni Dam |
Contract with the Implementing Agent signed in 2020 |
Contractor appointed. Site was handed over to the contractor on 08.09.2023. |
Construction is in progress |
2024-07-08 |
Completion date not yet due |
Completion date not yet due |
Budget R35,656,655 Exp R1,624,755 |
Numbi Gate - Mdhluli Cultural Centre |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 12% towards completion. |
Construction is in progress |
2024-03-26 |
Completion date not yet due |
Completion date not yet due |
Budget R33,009,600 Exp R2,681,202.38 |
Numbi Gate - Nkambeni Community Centre |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 8% towards completion |
Construction was halted due to land claim challenges. The Department is intervening. |
2024-03-26 |
Completion date not yet due |
Completion date not yet due |
Budget R23,724,670 Exp R2,485,333 |
Mpofu and Fordyce Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 28% towards completion |
Construction is in progress |
2023-12-02 |
Completion date not yet due |
Not Applicable |
Budget R3,370,866 Exp R1,404,286 |
Baviaanskloof Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 80% towards completion |
Construction is in progress |
2023-09-30 |
Completion date not yet due |
Not Applicable |
Budget R3,190,962 Exp R2,039,944 |
Cwebe and Dwesa Nature Reserves |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 20% towards completion |
Construction is in progress |
2023-12-01 |
Completion date not yet due |
Not Applicable |
Budget R4,599,194 Exp R830,624 |
Gariep Dam Resort |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 90% towards completion |
Construction is in progress |
2023-12-31 (Proposed revised Practical Completion date) |
Project is in progress |
Slow performance of the contractor. The project is now in penalties |
Budget R4,146,014 Exp R1,145,953 |
Phillip Saunders Resort |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 70% towards completion |
Construction is in progress |
2023-10-30 (Revised proposed Practical Completion date 2023-12-31) |
Completion date not yet due |
Additional scope of work requested by end under/client and extension of time under review to determine the completion date |
Budget R4,830,059 Exp R2,464,793 |
Maria Moroka Resort |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 70% towards completion |
Construction is in progress |
2023-09-15 (Revised proposed Practical Completion date 2023-12-31) |
Not Applicable |
Slow performance of the contractor. The project is now in penalties |
Budget R4,526,601 Exp R836,120 |
Sterkfontein Dam Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 99% towards completion. |
Construction is in progress |
2023-08-14 (Revised proposed Practical Completion date 2023-09-29) |
Not Applicable |
Slow performance of the contractor. The project is now in penalties |
Budget R5,187,975 Exp R2,773,746 |
Doornkloof Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 50% towards completion |
Construction is in progress |
2023-11-23 |
Completion date not yet due |
Not Applicable |
Budget R3,323,874 Exp R1,155,025 |
Rolfontein Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 60% towards completion |
Construction is in progress |
2023-11-23 |
Completion date not yet due |
Not Applicable |
Budget R3,968,732 Exp R1,576,356 |
Goegap and Witsand Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 59% towards completion |
Construction is in progress |
2023-11-23 |
Completion date not yet due |
Not Applicable |
Budget R7,879,259 Exp R3,187,007 |
Product Enhancement at Anton Lembede Museum Ethekwini Municipality (KZN) |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 10% towards completion |
Construction is in progress |
2024-02-28 |
Completion date not yet due |
Not Applicable |
Budget R22,066,867 Exp R915,043 |
Product Enhancement at Sol Plaatjie Museum (NW) |
Contract with the Implementing Agent signed in 2020 |
Contractor appointed. Construction in progress, about 1% towards completion |
Construction is in progress |
2023-12-29 |
Completion date not yet due |
Not Applicable |
Budget R22,066,867 Exp R915,043 |
Royal Khalanga |
Contract with the Implementing Agent signed in 2020 |
Construction in progress, about 26% towards completion |
Construction is in progress |
2024-03-25 |
Completion date not yet due |
Not Applicable |
Budget R16,610,039 Exp R2,252,210 |
Qatywa Lodge |
Project initially not completed in 2016. The project resumed in 2020 under the DBSA contract |
Construction in progress, about 45% towards completion |
Construction is in progress |
2024-03-12 |
Completion date not yet due |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 23,750,000 Exp: R 23,288,668 Current Phase Budget: R37,059,884 Exp: R17,434,079 |
Mthonsi Lodge |
Project initially not completed in 2016. The project resumed in 2020 under the DBSA contract |
Construction is in progress, about 73% towards completion |
Construction is in progress |
2023-11-30 |
Completion date not yet due |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 28,215,000 Exp: R 27,531,883 Current Phase Budget: R35,105,786 Exp: R19,299,000 |
QwaQwa Guest House |
Project initially not completed in 2018. The project resumed in 2020 under the DBSA contract |
Construction is in progress, about 98% towards completion. Practical completion anticipated for 30.10.2023. |
Construction is in progress |
2023-09-18 (Revised proposed Practical Completion date 2023-10-30) |
Completion date revised to Oct 2023 |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract. The design for the sewer had to be changed hence the delay in completion of the project |
Initial incomplete phase Budget: R21,875,949 Exp: R17,945,269.74 Current Phase Budget: R23,008,994 Exp: R18,960,588 |
Vredefort Dome Interpretation Centre |
Project initially not completed in 2012. The project resumed in 2020 under the DBSA contract |
Construction is in progress, about 37% towards completion. |
Construction was halted |
2023-10-17 |
Completion date not yet due |
The initial phase of the project was completed however there were structural defects due to geotechnical instability. Project is currently in the process of being completed through the DBSA contract. However, construction was stopped due to poor contractor performance. Contractor was terminated. DBSA currently looking for a replacement |
Initial incomplete phase Budget: R 3,009,453 Exp: R 2,927,652 Current phase Budget: R26,320,876 Exp: R6,695,541 |
Isibhubhu |
Project initially not completed in 2011. The project resumed in 2020 under the DBSA contract |
Construction in progress, about 80% towards completion |
Construction is in progress |
2023-09-16 (Revised proposed Practical Completion date 2023-11-15) |
Completion date revised to Nov 2023 |
The initial phase of the project was completed however not maintained over time. Project is currently in the process of being completed through the DBSA contract. Project experienced slow performance of contractor at commencement of project due to cash constrains and material sourcing challenges. DBSA loan facility assisted in the procurement of material and contractor performance improved. Suspension of work due to annual reed dance also delayed progress |
Initial incomplete phase Budget: R 15,000,000 Exp: R 14,889,708 Current Phase Budget: R33,149,775 Exp: R12,606,711 |
The Oaks |
Project initially not completed in 2019. The project resumed in 2020 under the DBSA contract |
Construction in progress, about 36% towards completion |
Construction is in progress |
2024-02-07 |
Completion date not yet due |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 26,550,216 Exp: R 25,483,869 Current phase Budget R28,542,771 Exp R6,151,499 |
Ngove |
Project initially not completed in 2016. The project resumed in 2020 under the DBSA contract |
Construction in progress, about 20% towards completion |
Construction is in progress |
2024-02-06 |
Completion date not yet due |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 20,133,951 Exp: R 19,993,013 Current Phase Budget: R 33,167,262 Exp: R1,824,192 |
Tisane |
Project initially not completed in 2015. The project resumed in 2020 under the DBSA contract |
Construction in progress, about 53% towards completion |
Construction is in progress |
2024-01-05 |
Completion date not yet due |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 18,810,000 Exp: R 18,299,799 Current Phase Budget: R30,374,169 Exp: R9,320,845 |
Lehurutshe Bird and Trophy Hunting |
Project initially not completed in 2009. The project resumed in 2020 under the DBSA contract |
Contractor procurement finalised and contractor appointed. Construction will commence in Oct 2023 |
Contractor procurement was finalised |
2024-03-26 |
Completion date not yet due |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 2,827,500 Exp: R 2,809,808 Current Phase Budget: R22,917,686 Exp: R1,099,089 |
Phiphidi Waterfall |
Project initially not completed in 2019. The project resumed in 2020 under the DBSA contract |
Contractor appointed. Site was handed over to the contractor on 08.09.2023. |
Contractor procurement was finalised |
2024-07-16 |
Completion date not yet due |
The initial phase of the project was not completed due contractual disputes with the Implementing Agent. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 29,477,099 Exp: R 23,264,771.67 Current Phase Budget: R23,350,230 Exp: R1,176,489 |
Muzi Pan |
Project initially not completed in 2015. The project resumed in 2020 under the DBSA contract |
Contractor procurement finalised. DBSA currently preparing contract documents. Construction will commence in Oct 2023. |
Contractor procurement was finalised |
Completion date will be determined once the contract is signed |
Completion date is yet to be determined |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 12,447,480 Exp: R 11,887,690 Current Phase Budget: R18,376,724 Exp: R540,983 |
Manyane Lodge |
Project initially not completed in 2016. The project resumed in 2020 under the DBSA contract |
Contractor procurement phase. Tender evaluation has been completed |
Contractor procurement is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
The initial phase of the project not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Initial incomplete phase Budget: R 48,465,113 Exp: R 47,884,114 Current Phase Budget will be disclosed after contractor is appointed |
Lotamoreng Dam |
Contract with the Implementing Agent signed in Nov 2020 |
Construction tender went out on 04.09.2023. Briefing was on 12.09.2023. Tender closes on 28.09.2023 This is a re-tender. |
Contractor procurement is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
VhaTsonga |
Project initially not completed in 2011. The project resumed in 2020 under the DBSA contract |
Contractor procurement stage |
Contractor procurement is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
The initial phase of the project was not completed due to poor workmanship. Project is currently in the process of being completed through the DBSA contract |
Budget and expenditure on the initial incomplete phase Budget: R 9,185,000 Exp: R 9,068,064 Current Phase Budget will be disclosed after contractor is appointed |
Kamiesburg |
Project initially not completed in 2011. The project resumed in 2020 under the DBSA contract |
Design Development stage |
Design development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
The initial phase of the project was not completed due to budget shortfall. Project is currently in the process of being completed through the DBSA contract |
Budget and expenditure on the initial incomplete phase Budget: R 5,100,000 Exp: R 4,815,074 Current Phase Budget will be disclosed after contractor is appointed |
Platfontein |
Project initially completed in 2017 however with structural defects. The project resumed in 2020 under the DBSA contract |
Concept stage |
Concept development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
The initial phase of the project was completed however there were structural defects post completion Project is currently in the process of being completed through the DBSA contract |
Budget and expenditure on the initial incomplete phase Budget: R 32,206,320 Exp: R 32,072,057 Current Phase Budget will be disclosed after contractor is appointed
|
Hluleka Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Concept stage |
Concept development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
JL Dube Precinct |
Contract with the Implementing Agent signed in 2020 |
Design Development stage |
Design development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Suikerbosrand Nature Reserve |
Contract with the Implementing Agent signed in 2020 |
Contractor tender evaluation |
Contractor procurement is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Product Enhancement at McGregor Museum (NC) |
Contract with the Implementing Agent signed in 2020 |
Contractor tender evaluation |
Contractor procurement is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Product Enhancement at AmaHlubi Cultural Heritage (KZN) |
Contract with the Implementing Agent signed in 2020 |
Concept stage |
Concept development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Product Enhancement at Lehurutshe Liberation Heritage Museum (NW) |
Contract with the Implementing Agent signed in 2020 |
Concept stage |
Concept development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed is appointed |
Tourism development at Orange River Mouth (NC) as part of the Indi-Atlantic Route |
Contract with the Implementing Agent signed in 2020 |
Design Development stage only. Will not proceed to the construction phase |
Design development is in progress |
Design planning to be completed in Oct 2023 |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Tourism Development at Hole in the Wall (EC) as part of the Indi-Atlantic Route |
Contract with the Implementing Agent signed in 2020 |
Design Development stage only. Will not proceed to the construction phase |
Design development is in progress |
Design planning to be completed in Oct 2023 |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Tourism development at Harold Johnson Nature Reserve (KZN) as part of the the Indi-atlantic Route |
Contract with the Implementing Agent signed in 2020 |
Design Development stage only. Will not proceed to the construction phase |
Design development is in progress |
Design planning to be completed in Oct 2023 |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Mahikeng Hotel School |
Contract with the Implementing Agent signed in 2020 |
Concept stage |
Concept development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
Pilanesberg Game Reserve |
Contract with the Implementing Agent signed in 2020 |
Professional Service Provider procurement |
Professional Service Provider Procurement stage |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
SKA Visitor Interpretation Centre |
Contract with the Implementing Agent signed in 2021 |
Design development stage |
Design development is in progress |
Completion date will be determined once the contractor is appointed |
Completion date is yet to be determined |
Not Applicable |
Budget will be disclosed after contractor is appointed |
02 October 2023 - NW3142
Herron, Mr BN to ask the Minister of Police
(1) (a) What National Training Standards apply to (i) crime prevention wardens (CPWs), (ii) law enforcement officers (LEOs) and (iii) leamer law enforcement officers (LLEQs), (b) what are the legislative provisions they rely on to provide for the specified training, (c) on what date was it gazetted and (d) will he furnish Mr B N Herron with a copy thereof; (2) what is the status of categories of security services not provided for in terms of the Constitution of the Republic of South Africa, 1996, and/or any national legislation, performing peace officer functions armed with firearms; (3) if the CPWs, LEOs and LLEOs are not lawfully established and/or operating in reliance of national legislation, what steps does he intend to take in each case?
02 October 2023 - NW2947
Matumba, Mr A to ask the Minister of Tourism
(a) How has the One Global Brand Activation aligned the work of (i) Brand SA, (ii) provinces and (iii) municipalities in the international markets and (b) what are the planned summer campaigns for the coming summer season in the Republic?
Reply:
a) How has the One Global Brand Activation aligned the work of:
`I have been informed by South African Tourism that a number of global brand activations were delivered across various markets and platforms in collaboration with key stakeholders. Some of the key platforms that were activated include World Travel Market in London, ITB in Berlin, Arabian Travel Market in Dubai and BRICS Outreach programme in Nigeria.
(i) Brand SA in the international markets
Where the opportunity for collaboration exists, SA Tourism works with Brand SA for joint activations. For the period under review, the BRICS outreach platform presented an opportunity for collaboration with Brand SA and BRICS Business Council. The activation included a stakeholder engagement with both government and business counterparts in Nigeria to forge relations. Furthermore, the platform presented a leveraging opportunity to promote the BRICS Summit.
(ii) Provinces in the international markets and (iii) Municipalities in the international markets
In terms of collaboration with provinces and municipalities, the activations were delivered in a form of showcasing destination experiences at the strategic platforms abroad. This was done through exhibitions and further showcasing of SMMEs arts and crafts to enhance the destination showcase.
(b) What are the planned summer campaigns for the coming summer season in the Republic.
The Sho’t Left “Gimme Summer That Sho’t Left” summer campaign was launched in the Eastern Cape on 19 September 2023. The campaign creates a good platform to promote an inclusive South Africa as an appealing and must-experience tourism destination for both Domestic and International travellers while showcasing a wide variety of experiences including Hidden Gems, during the Festive season.
This is also an opportunity for South Africa to showcase how welcoming and inclusive we are to our Regional and International Tourists. Therefore, through this campaign, the Hub teams will leverage and showcase South Africa’s season readiness to welcome visitors in line with their insights for their respective markets.
Underpinning this campaign will be the rollout of the “Make Someone’s Day” initiative which is part of the overall Welcome Programme that drives inclusivity to mitigate unpleasant incidents. The Welcome Program seeks to inspire and educate South African tourism role players and ordinary South Africans to exceed tourist expectations.
The “Make Someone’s Day” campaign, is positioned to showcase and highlight the importance of trade in the tourism value chain. We create and sustain sector partnerships with the trade through information sharing, toolkit developments, training and fact sharing. Through these we developed inclusive Welcome Training modules to help our partners upskill their frontline service staff.
The main objectives of the campaign are as follows:
- To inspire South Africans to travel and spend more during this coming Festive Season.
- To invite and inspire travellers from outside of South Africa to choose to come visit
South Africa during the festive season and beyond
- To encourage South Africans to explore more provinces (Geographic Spread)
- To showcase the wide variety of tourism experiences on offer in South Africa for both
domestic and international travellers through engagements with the travel trade and
deals loaded on the South African Tourism trade platform.
- To ensure increased collaboration between SAT and Private Sector/Other Stakeholders
- To ensure the destination is inclusive, warm and welcoming to all travellers
The campaign, co-created with provinces and the private sector, will be rolled out across all media platforms including TV, Radio, Out of Home, digital and will be supported through activations in provinces. This deal driven campaign will run from 1 October 2023 to 14 January 2024.
02 October 2023 - NW2679
Schreiber, Dr LA to ask the Minister of Higher Education, Science and Innovation
Whether, with reference to his replies to question 3520 on 27 October 2022 and to question 45 on 24 February 2023, the amendment to the Language Policy Framework for Higher Education Institutions to provide an explicitly inclusive definition of indigenous languages and/or resolve technicalities around the definition of indigenous language has been duly published in the Government Gazette; if not, what are the reasons that the amendment has not been implemented despite his repeated undertakings to do so; if so, what are the relevant details?
Reply:
The definition of “indigenous languages” in the Language Policy Framework for Public Higher Education Institutions, published on 30 October 2020 has been revised in line with legal advice the Department of Higher Education and Training has received on the matter. The revised definition was published on 7 July 2023 in Government Gazette no 48923, under the title, “Amendment of the Definition on the Language Policy Framework For Public Higher Education Institutions, Determined in Terms of Section 27(2) of the Higher Education Act, 101 of 1997 as amended”.
02 October 2023 - NW2962
Mohlala, Ms MR to ask the Minister of Water and Sanitation
Whether his department has moved for critical water and sanitation infrastructure projects to be declared as national key points, with the necessary security to reduce the countrywide theft and vandalism of infrastructure, which impacts service delivery to communities; if not, what is the position in this regard; if so, what are the relevant details?
Reply:
Yes, as an asset owner the Department had some of the national water resource infrastructure declared as National Key Points, dependent on the criticality of specific government water schemes. All of these National Key points are guarded by qualified armed security guards which are officials in the department whereas non-strategic assets are guarded by private security companies. It must be noted that due to the nature of conveyance systems (including canals, pipelines and tunnels), it would be challenging to have sufficient security measures in place to completely mitigate the risk of vandalism.
However, there are operating and maintenance agreements with water boards and water user associations for government water schemes that are remotely located. These institutions assist with the safeguarding of these assets.
Water Boards have taken similar steps to have some of their critical infrastructure declared as National Key Points, but more is to be done for similar classification strategies to be followed at the municipal level; regarding local water and sanitation assets (owned by municipalities).
---00O00---
02 October 2023 - NW3101
Boshoff, Dr WJ to ask the Minister of Higher Education, Science and Innovation
(1)What (a) progress has been made on the fencing of the Square Kilometre Array (SKA) core area, (b) conditions were agreed to with SANParks to manage the area and (c) date was set for SANParks to commence with the management of the specified area; (2) whether any community members and/or farmers have received access to the internet connection of the SKA as was indicated to the Portfolio Committee on Higher Education, Science and Innovation during the visit to the SKA; if not, why not; if so what are the relevant details?
Reply:
(1)
a) The project to erect a fence surrounding the land declared as the Meerkat National Park, which includes the core site of the SKA, is managed by the South African Radio Astronomy Observatory (SARAO). A tender for the construction of the fence was published on 13 June 2023 and closed on 11 August 2023. SARAO is currently evaluating the submissions received. The project is expected to be completed approximately 30 months after the award of the tender.
b) SANParks was appointed to manage the NRF land acquired for the purpose of hosting the SKA project. The NRF concluded a management agreement with SANParks and the land was subsequently declared as a national Park. SANParks has developed a park management plan which sets out the long-term vision, objectives and strategies for the park. The Park Management Plan was approved by the Minister of Forestry, Fisheries and Environment on 29 September 2022.
c) The area declared as the National Park is currently under the management of SANParks. The following management measures are being implemented:
- putting in place the necessary physical, human and financial resources required to run the Meerkat National Park;
- introducing measures and mechanisms for water management;
- rolling out general security measures through demarcation and identification of the park, and enhanced infrastructure such as inspection roads;
- implementing an alien invasive species management programme through the Extended Public Works Program (EPWP) resources;
- implementing a ‘cleaning and greening’ initiative which employed up to 120 youths from the local communities; and
- assisting farmers to maintain their boundary fences as an interim mitigation measure whilst the Meerkat National Park fence is being erected.
2. As part of its socioeconomic development initiatives in the SKA area the South African Radio Astronomy Observatory (SARAO) continues to provide internet connectivity to the people in the area, including the farmers. To date, 368 individuals are receiving subsidised broadband internet services via commercial satellite service providers. These programs continue to be reviewed on an ongoing basis to ensure competitive service offerings and pricing.
02 October 2023 - NW2560
Ngcobo, Mr S to ask the Minister of Higher Education, Science and Innovation
What measures has his department taken to resolve issues regarding the National Student Financial Aid Scheme, including the problems created by the new payment system, in institutions of higher learning across the Republic?
Reply:
The Department met with NSFAS board and requested that they provide a turn-around strategy to the Minister. Furthermore, NSFAS submitted an audit plan to the Minister on 04 September 2023, which the Department will monitor monthly. In addition, the Department has been engaging with the World Bank’s International Finance Corporation (IFC) and NSFAS to ensure further research on the price cap of student accommodation is concluded and used to inform policy decisions. The Department intends to extend the IFC focus to include an assessment of the accreditation of accommodation system established by NSFAS with the intent to resolve the grading system. The Department facilitated a meeting between National Treasury and NSFAS, and with the assistance of Information Technology (IT) experts, advised NSFAS on a more appropriate IT strategy before additional funds were transferred to NSFAS to support IT improvements. With regards to the payment system, the Department is awaiting the SIU and Werksmans Attorneys’ findings before it makes further decisions.
02 October 2023 - NW2946
Matumba, Mr A to ask the Minister of Tourism
What (a) activities were included in the Global Tourism Brand Campaign in the period under review and (b) positive (i) gains and/or (ii) challenges have been experienced in implementing the Global Advocacy Programme?
Reply:
a) What activities were included in the Global Tourism Brand Campaign in the period under review.
I have been informed by South African Tourism (SAT) that reinstating our brand after the COVID-19 global pandemic with the ‘Live Again’ campaign was critical in driving sustainable economic growth, raising awareness of South Africa as a tourism destination, and aiding efforts to reclaim our position in the global travel community.
The ‘Live Again’ global brand campaign, which was launched in February 2022 in responding to reigniting the global demand, which is one of the strategic interventions as part of the sectoral recovery plan, was rolled out in FY22/23.
SAT produced a global campaign AV that was seeded in key source markets through a global media buy. The overall objective of the campaign was to increase awareness and build positivity towards the destination. The media buy included the following key platforms:
CNN YouTube National Geographic
BBC Twitter/X Facebook
Search WeChat Programmatic
Premium Display Online Travel Agents
(b) (i) What positive gains have been experienced in implementing the Global Advocacy Programme.
The main objective of the Global Advocacy campaign is to garner a positive image of South Africa and its offering. Through various interactions and activations, South African Tourism has participated in platforms with individuals with influence driving and advancing a positive narrative about the country.
Examples of these are:
- During Internationale Tourismus Börse (ITB) in Germany in early March 2023, both the Deputy Minister, Fish Mahlalela as well as Ambassador Stone Sizani spoke candidly about the initiatives and discussion in government around issues of safety and security. This gave the media covering the event an indication that the issue is being addressed at government level.
- During Meetings Africa 2023, we also had a few leading influential business events voices positively advocate for South Africa as not only a capable business events host but also as a country that has an in-depth knowledge economy. In various activities through our hub teams, work has been done in advancing global advocacy initiatives including working with various embassies and missions.
- During the State of the Nation address earlier this year, CNN’s Richard Quest visited the country and recorded a series of inserts in Cape Town. He showcased the best of the region. As a leader in shaping business opinion, his recording of his show in South Africa and featuring several positive human-interest stories contributed in driving a positive narrative about South Africa.
- Other noteworthy areas where we have seen gains that can also be attributed to efforts of the Global Advocacy programme is around airlift. Over the last year, we have seen a number of airlines reintroducing direct routes to South Africa from various countries. This is surely a vote of confidence and trust in our destination.
(ii) What positive challenges have been experienced in implementing the Global Advocacy Programme.
The biggest challenge around Global Advocacy is still issues that affect the overall reputation of South Africa. These include reported cases of safety and security especially those affecting the tourists but those also affecting citizens. Tourists are also beginning to enquire about load shedding. Although the tourism industry continues to operate, tourism businesses experience disruptions and delays in operations.
Picking up learnings of the past few years of load shedding, some businesses have put measures in place to offset the effects of load shedding. Some have installed UPS units (Uninterrupted Power Supply units), or other back power supplies such as generators. Furthermore, load shedding may cause delays in traffic, due to traffic lights not working, when tourists are commuting to reach attractions around the country. Prolonged periods of load shedding such as Stage 6 may also lead to disruption of other tourism and related experiences.
02 October 2023 - NW2987
Mbabama, Ms TM to ask the Minister of Water and Sanitation
With reference to the draft regulations relating to the Procedural Requirements for Water Use Licence Applications that were published on 19 May 2023, and with regard to water use licences issued in terms of section 21(a) and (b) and section 21(d) of the National Water Act, Act 36 of 1998, to farmers or farming and/or agriculture entities, what (a) is the total number of applications that were received in each category in the past three financial years and (b) number of the specified applications were approved in each specified year (i) within 30 days, (ii) within 60 days, (iii) within 90 days and (iv) after 90 days of receipt thereof?
Reply:
a) The total number of applications that were received in terms of section 21(a) and (b) and section 21(d) from farmers or farming and/or agriculture entities in the past three financial years are indicated in the table below:
Year |
Number of received applications |
2020 |
395 |
2021 |
355 |
2022 |
393 |
Total |
1143 |
b) The number of the specified applications that were issued with licences in each specified year (i) within 30 days, (ii) within 60 days, (iii) within 90 days and (iv) after 90 days of receipt thereof?
Licences issued |
|||||
Year of application Submission |
30 days |
60 days |
90 days |
over 90 days |
Total |
2020 |
0 |
0 |
1 |
165 |
166 |
2021 |
3 |
15 |
26 |
113 |
157 |
2022 |
8 |
15 |
11 |
168 |
202 |
Total |
11 |
30 |
38 |
446 |
525 |
---00O00---
02 October 2023 - NW2885
Lees, Mr RA to ask the Minister of Transport
What are the (a) relevant details of all contracts and/or arrangements that the Road Accident Fund (RAF) has had with the Sunshine Hospital, (b) detailed reasons for terminating any of the RAF contracts and/or arrangements with the specified hospital, (c) relevant details of all court judgments granted in favour of the hospital and against the RAF and (d) relevant details of the total amounts of all (i) court judgments and (ii) cost orders granted against the RAF in favour of the hospital?
Reply:
What are the
a) relevant details of all contracts and/or arrangements that the Road Accident Fund (RAF) has had with the Sunshine Hospital,
The RAF signed a Cooperation agreement with Sunshine Hospital in November 2007. The agreement had no expiry date. Upon review it was found that the relationship is no longer beneficial to the RAF business. Sunshine hospital was engaged and informed of the decision to terminate the relationship through a letter in July 2018.
b) detailed reasons for terminating any of the RAF contracts and/or arrangements with the specified hospital,
The agreement was not compliant with the RAF’s corporate governance prescripts whereby all signed agreements had an end date. The relationship was not relevant to RAF business and Sunshine was misrepresenting the nature of the relationship claiming to be a “RAF hospital”. There is evidence of sown cases of possible corrupt practises by Sunshine.
(c) Below is the list of all transaction in favour of Sunshine Hospital, listed by category, for the period 1 April 2014 to date:
Overall,
There were 28,941 transactions to the value of R3.53 billion of which, 1 132 with a value of R18.75 million were due to a court judgement.
(d) Below is the list of details of the total amounts of all (i) court judgments and (ii) cost orders granted against the RAF in favour of Sunshine Hospital.
In summary:
Plaintiff Attorney Capital are costs for the court order judgement, the Plaintiff Attorney Costs are legal costs awarded to Sunshine Hospital. Interest Costs are in relations to the capital awarded to Sunshine Hospital in the Judgement. Sherrif & Writ costs are costs of attachment and execution.
02 October 2023 - NW2703
King, Ms C to ask the Minister of Higher Education, Science and Innovation
(1)What total number of beds are available for students at (a) private and (b) public student accommodation providers; (2) what total number of the 2023 National Student Financial Aid Scheme students were evicted due to defunding at private student accommodation; (3) whether he had conducted a survey on the state of student accommodation in the Republic in the past three academic years; if not, why not; if so, (4) whether he will furnish Ms C V King with the report of the survey; if not, why not; if so, what are the relevant details; (5) what are the details of the Draft Multifaceted Student Housing Strategy that has been approved by the Director-General?
Reply:
- The findings of an International Finance Corporation study which was supported by the Department of Higher Education and Training (the Department) are that as of 2020, there were 125 891 beds by public student accommodation providers (TVET Colleges and Universities) and 97 219 beds by private student accommodation providers.
- We will need to request this data from the institutions. We will therefore await advice on whether we should proceed to do so and how long should we give them to provide such information. We may not receive a response from all of them irrespective of the response time we give them.
- The survey was conducted by the International Finance Corporation in 2020, and it was supported by the Department. The report was released in April 2021.
- The report is attached at Annexure A of this response.
- The Strategic Planning Unit may have incorrectly reported that there was a draft strategy and that it was approved by the Director-General. The strategy was never drafted. We will therefore await advice on the way forward.
02 October 2023 - NW2982
De Freitas, Mr MS to ask the Minister of Tourism
(1) With reference to tourism projects undertaken by the Development Bank of Southern Africa (a) in the past three financial years and (b) since 1 April 2023, what are the processes, procedures, mechanisms and timelines to monitor (i) the progress and (ii) status of each project; (2) (a) who is responsible for such monitoring, (b)(ii) how and (iii) to whom are project status reports reported and (c) what processes, procedures and/or mechanism are in place should a project not meet what is required or when deadlines are not met?
Reply:
1. (a) 2020-21
1.(i) What are the processes, procedures, mechanisms and timelines to monitor the progress of each project.
- I have been informed by the Department that the National Department of Tourism has an existing Memorandum of Understanding (MOU) with the Development Bank of Southern Africa (DBSA). The MOA is valid from November 2020 to November 2023.
- The Department uses the terms and conditions of the MOA to ensure compliance by the DBSA. The MOA is accompanied by an Infrastructure Programme Implementation Plan (IPIP) which is informed by the National Treasury’s Framework for Infrastructure Delivery and Procurement Management (FIDPM).
- The IPIP compels the DBSA to seek concurrence / sign off from the Department in order to move on to the next stage of the project.
- The Department will then sign off or concur at each project stage for DBSA to move on to the next stage.
- The Department has wel- established governance structures to manage and monitor the implementation of its infrastructure programme through the DBSA; namely, Programme Management Meetings, chaired by the DDG: Destination Development and Steering Committee Meetings, chaired by the DG.
- The Minister also meets Quarterly with the DBSA .
- The Department receives monthly and quarterly progress and expenditure reports from the DBSA.
- The Departmental Project Managers conduct site visits on a monthly basis.
(1)(ii) What are the processes, procedures, mechanisms and timelines to monitor the status of each project
Refer to (1) (i) (a).
(2)(a) Who is responsible for such monitoring?
- Departmental Project Managers
- Directors
- Chief Directors
- DDG
- DG
(2)(b)(ii) How are project status reports reported
- Presentations at Progress and Steering Committee meetings
- Monthly Progress Reports
- Quarterly Progress Reports
(2)(b)(iii) To whom are project status reports reported
- At Progress Meetings - to NDT DDG: Destination Development and Head of Infrastructure Delivery: DBSA.
- At Steering Committee Meetings - to DG and Group Executive: Infrastructure Delivery, DBSA.
(2)(c) What processes, procedures and/or mechanism are in place should a project not meet what is required or when deadlines are not met.
- DBSA and the appointed service providers have a contract in place which outlines processes and procedures.
- A default notice will be issued to an underperforming Contractor according to the Contract being utilised.
- If the Contractor has been delayed, they will claim for Extension of Time based on the event and Contract.
- A Contractor will be requested to put in place a Recovery /Catch up Plan to be strictly monitored.
- DBSA offers loans to contractors with cash-flow challenges which are affecting project progress.
- DBSA may terminate contracts of contractors who continuously fail to remedy non-performance.
- Where necessary, constant monitoring, supervision and also site visits are conducted by Principals to projects with persistent challenges delaying project completion.
(1) (a) and 2 (a-c) 2021-22 Same as above
(1) (a) and 2 (a-c) 2022-23 Same as above
(1) (b) and 2 (a- c) April 2023 Same as above
02 October 2023 - NW3034
Phillips, Ms C to ask the Minister of Water and Sanitation
Whether, in light of the water shortage in the Bojanala district, he will furnish Mrs C Phillips with a copy of the water use licence of a certain company (name and details furnished), which applied for environmental authorisation in terms of section 24G(1) of the National Environmental Management Act, Act 107 of 1998, as amended, for an unlawful development of a chrome wash plant on Portion 71 of Farm Groenkloof 464-JQ in Madibeng Local Municipality, North West; if not, (a) why not and (b) what actions will he take against the company for not being in possession of a valid water use licence; if so, on what date?
Reply:
a) According to the records of the Department of Water and Sanitation (DWS), there is no authorisation that has been issued for water use activities associated with a chrome wash plant located on Portion 71 of Farm Groenkloof 464-JQ in Madibeng Local Municipality, North West.
The DWS has taken steps to address the alleged unlawful development of a chrome wash plant on Portion 71 of Farm Groenkloof 464-JQ and has taken the following actions:
- Site investigation was conducted on 19 September 2023
- The DWS is in the process of issuing a Notice of Intention to issue a Directive in terms of National Water Act to the company responsible for the unlawful water use through development of the chrome wash plant.
b) Further administrative action to be taken and compliance with the stipulated timeframe will be guided by the response of the owners of the chrome wash plant. Should the owners of this wash plant fail to comply with the prescripts of the Notice to be issued by DWS, the Department will proceed with further enforcement actions.
---00O00---
02 October 2023 - NW2980
De Freitas, Mr MS to ask the Minister of Tourism
(a) What are the processes, procedures, mechanisms and timelines to monitor (i) the progress and (ii) status of each tourism project in the (aa) past three financial years and (bb) current financial year, (b) who is responsible for such monitoring, (c) how is monitoring conducted and (d) to whom are project status reports presented and/or submitted?
Reply:
INFRASTRUCTURE PROJECTS NOT IMPLEMENTED BY DBSA
(aa) 2020-21
(a)(i) What are the processes, procedures, mechanisms and timelines to monitor the progress of each tourism project
I have been informed by the Department that it appointed various entities to implement its tourism infrastructure projects. The relationship between the Department and these entities is regulated through Memoranda of Agreement (MOAs).
Each project has a Project Steering Committee (PSC) established to oversee the implementation of the project.
- The Department receives monthly progress and expenditure reports from entities.
- Entity coordination meetings are held with entities individually and collectively.
- The Departmental Project Managers conduct site visits on a monthly basis.
- The Department issues management letters to non-performing entities where outputs are not satisfactory.
- Entities with their appointed service providers have a contract in place which outlines processes and procedures.
- The entity is expected to issue a default notice to an underperforming contractor according to the contract being utilised.
- If the contractor has been delayed, they will claim for Extension of Time based on the event and contract.
- A contractor will be requested to put in place a Recovery /Catch up Plan to be strictly monitored.
- The entity may terminate contracts of contractors who continuously fail to remedy non-performance.
- Where necessary, constant monitoring, supervision and also site visits are conducted by Principals to projects with persistent challenges delaying project completion.
(a)(ii) What are the processes, procedures, mechanisms and timelines to monitor the status of each tourism project
Refer to (1) (i) (aa).
(b) Who is responsible for such monitoring
Project Managers
(c) How is monitoring conducted
- Site visits
- PSC meetings
- Progress reports
(d) To whom are project status reports presented and/or submitted
- Director
- Chief Director
- DDG: Destination Development
(aa) 2021-22 (a)– (d) same as above
(aa) 2022-23 (a)– (d) same as above
(bb) 1 April 2023 (a)– (d) same as above
02 October 2023 - NW2945
Matumba, Mr A to ask the Minister of Tourism
What (a) new insights were received from the Integrated Digital and Analytics Operating Framework and (b) are the relevant details in this regard?
Reply:
(a) What new insights were received from the Integrated Digital and Analytics Operating Framework?
I have been informed by South African Tourism (SAT) that the framework provides real-time insights into the performance of digital campaigns. This includes what travelers are interested in and looking for. The data comes from digital analytics tools that SAT has a license for, namely Google Analytics and Meltwater, can be extracted at any point.
The insights extracted include but are not limited to:
1. What travelers are specifically looking for on search engines used across the conversion curve and while experiencing the country;
2. The traveler sentiment and conversation opportunities at each stage of the conversion curve, inclusive of arrival and experiencing the country. The departure survey remains an established research method by the Analytics division at SA Tourism to extract departure related information. While the digital analytics data can complement the formal research, it is currently used to inform digital marketing campaign performance and improvement opportunities.
3. The type of devices travelers use to consume specific types of content;
4. How long it takes for Domestic travelers to book; - Taken from user behavior on Sho’t left and any advertising leading users to Sho’t left. Since the first time the user saw something on Sho’t left all the way until they clicked on “Book Now”.
5. Provincial demand for domestic travel. – It is demand to travel. The location where online users, in South Africa, are searching from to find Shotleft travel deals.
(b) What are the relevant details in this regard?
The integrated digital and analytic-operating framework is designed to deliver 3 goals across SA Tourism locally and globally;
- Standardize how SA Tourism business units measure the individual digital marketing campaign performance.
- Centralize and standardize the storage and management of data;
- Gather travel demand and experience data for ingestion into the Visitor Information System;
The suite of channels is that which SA Tourism uses to market the country and or engage with sector stakeholders. They are: CRM, Websites, Apps, Social Media, Paid Media, Search Engines for which there are standard tools to measure using Google Analytics, Meltwater and Microsoft.
This forms part of the 2025 strategic journey to champion digital for the sector and is an APP target.
02 October 2023 - NW3042
Herron, Mr BN to ask the Minister of Police
(1) With reference to sections 199(1) and 199(3) of the Constitution of the Republic of South Africa, 1996, which provides that the security services of the Republic consists of a single police service, unless a security service is established in terms of national legislation, in terms of which the SA Police Service Act, Act 68 of 1995, provides for the establishment of municipal police services as a peace officer (details furnished), on which legislative provisions do Gauteng crime prevention wardens (CPWs) rely to operate as a security service; (2) on which legislative provisions do (a) municipal law enforcement officers (LEOs), who are not members of a municipal police service, rely to conduct crime prevention activities and (b) they rely for defining and/or establishing (i) CPWs and (ii) LEQs?